HomeMy WebLinkAboutReso 44-18 Public Art Agreement with Sculptural Solutions for a Veterans Art Project at Don Biddle Community Park RESOLUTION NO. 44— 18
A RESOLUTION OF THE CITY COUNCIL
OF THE CITY OF DUBLIN
* * * * * * * * * * *
APPROVING A PUBLIC ART AGREEMENT WITH SCULPTURAL SOLUTIONS INC.
FOR A VETERANS ART PROJECT AT DON BIDDLE COMMUNITY PARK
WHEREAS, the 2016-2021 Capital Improvement Program includes a project to design,
fabricate and install permanent public art at Don Biddle Community Park (formerly known as Dublin
Crossing Community Park); and
WHEREAS, the City Council selected this location as the site for a Veterans Art Project
honoring military veterans and active duty personnel; and
WHEREAS seven public artists who pre-qualified according to the Public Art Master Plan
process to design monumental sculptures were invited to submit design proposals to design, fabricate
and install a Veterans Art Project; and
WHEREAS, the Veterans Art proposal by Steven Whyte was recommend by the Veterans Art
Selection Committee, Heritage and Cultural Arts Commission and Parks and Community Services
Commission and approved by the City Council; and
WHEREAS, Steven Whyte has demonstrated ability and availability to perform said services;
and
WHEREAS, Steven Whyte contracts his artistic services through his company, Sculptural
Solutions Inc.
NOW, THEREFORE, BE IT RESOLVED that the City Council of the City of Dublin does
hereby approve the Agreement with Sculptural Solutions Inc., attached as Exhibit A, and authorizes
the City Manager to execute the Agreement and make any other minor amendments as necessary to
carry out the intent of this Resolution.
PASSED, APPROVED AND ADOPTED this 15th day of May 2018, by the following vote:
AYES: Councilmembers Goel, Gupta, Hernandez, Thalblum and Mayor Haubert
NOES:
ABSENT:
ABSTAIN:
ayor
ATTEST:
avo L P c? i)
City Clerk
Reso No. 44-18, Adopted 5/15/2018, Item No. 4.4 Page 1 of 1
PUBLIC ART AGREEMENT BETWEEN
THE CITY OF DUBLIN AND SCULPTURAL SOLUTIONS INC.
THIS AGREEMENT is made by and between the City of Dublin ( "City ") and Sculptural Solutions Inc.
( "Artist ") as of April 17, 2018, for the purposes and on the terms and conditions set forth below.
WHEREAS, the City requires the services of Artist to perform artistic services described in the Agreement for a
public art project as described under Section 8.58 of the Dublin Municipal Code; and
WHEREAS, the City is authorized by Section 2.36.050 of the Dublin Municipal Code to contract for the
specialized services of the artist contemplated by this Agreement; and
WHEREAS, Artist is qualified and desires to perform the artistic services required by the City as set forth in this
Agreement; and
WHEREAS, the City Council, on March 20, 2018, authorized the City Manager to negotiate an agreement
between City and Artist for the preparation of a final design, fabrication and installation for a public art sculpture at the
future Don Biddle Community Park, to be located at the intersection of Dublin Boulevard and Columbus Street;
NOW, THEREFORE, in consideration of the mutual promises contained herein, the parties hereto agree as
follows:
AGREEMENT
Section 1. SERVICES. Subject to the terms and conditions set forth in this Agreement, Artist shall provide to
City the services necessary to provide the artwork ( "Work ") described in the Artist Proposal described in Exhibit A,
and in the Scope of Work attached as Exhibit B at the time and place, and in the manner specified therein. In the
event of a conflict in or inconsistency between the terms of this Agreement and Exhibit B, the Agreement shall
prevail
1.1 Term of Services. The term of this Agreement shall begin on the date first noted above and shall
end on the date of completion specified in Exhibit B, and Artist shall complete the Work described
in Exhibit A prior to that date, unless the term of the Agreement is otherwise terminated or
extended, as provided for in Section 17. The time provided to Artist to complete the services
required by this Agreement shall not affect the City's right to terminate the Agreement, as provided
for in Section 17.
1.2 Standard of Performance. Artist shall perform all services required pursuant to this Agreement in
the manner and according to the standards observed by a competent practitioner of the profession
in which Artist is engaged in the geographical area in which Artist practices its profession.
1.3 Assignment of Personnel. Artist shall assign only competent personnel to perform services
pursuant to this Agreement. In the event that City, in its sole discretion, at any time during the term
of this Agreement, desires the reassignment of any- such persons, Artist shall, immediately upon
receiving notice from City of such desire of City, reassign such person or persons.
Public Art Agreement between the April 17, 2018
City of Dublin and Sculptural Solutions Inc. Page 1 of 18
1.4 Time. Artist shall devote such time to the performance of services pursuant to this Agreement as
may be reasonably necessary to meet the standard of performance provided in Section 1.1 above
and to satisfy Artist's obligations hereunder.
Section 2. SCOPE OF WORK: Artist shall provide a final design, fabrication and installation of a monumental
sculpture honoring military veterans and active duty personnel for the Don Biddle Community Park public art project
as more specifically described in Exhibits A and B of this Agreement.
2.1 The City shall be responsible for providing the Artist, without cost, copies of designs, drawings,
reports, and other relevant data needed by the Artist to design and execute the Project.
2.2 The Artist shall, whenever required during the term of this Agreement, present to the City in writing,
drawing, or other appropriate media for further review and approval any significant changes in the
scope, design, color, size, material, utility, support requirements, texture, or location of the site or the
Work. A significant change is any change that could affect the future installation, scheduling, site
preparation, or maintenance of the Work, or the concept of the Work as represented in the original
concept design included in Exhibit A.
2.3 The City may, at any time, request the Artist in writing to (a) revise portions of the services that
he /she has previously completed in a satisfactory manner; (b) delete portions of the Scope of the
Work that the Artist has not yet performed; (c) perform additional work beyond the Scope of Work to
be provided in Exhibit B; and, (d) make other changes within the General Scope of the Work to be
performed under this Agreement. In the event of such a written request, the Artist may, but shall not
be obligated to agree to any such request.
2.4 In the event the request for change is agreed to by the Artist, this Agreement shall be amended, in
writing, specifying the agreed changes, including, but not limited to, a description of services,
additional budget, payment schedule, and timetable. In the event that the Artist does not agree to the
request, the City shall be entitled to terminate the Agreement for cause pursuant to Article 17 herein.
2.5 No services for which additional compensation will be charged shall be provided by the Artist without
the prior written authorization by the City,
Section 3. COMPENSATION. City hereby agrees to pay Artist a sum not to exceed $500,000.00 as specified
in Exhibit C, notwithstanding any contrary indications that may be contained in Artist's proposal, for services to be
performed under this Agreement; or subject to additional amounts for any revisions requested and change order
approved by the City as provided for in Section 2.3 above or elsewhere in this Agreement. In the event of a conflict
between this Agreement and Artist's proposal, attached as Exhibit A, regarding the amount of compensation, the
Agreement shall prevail. City shall pay Artist for services rendered pursuant to this Agreement at the time and in the
manner set forth herein. The payments specified in Exhibit C shall be the only payments from City to Artist for
services rendered pursuant to this Agreement. Artist shall submit all invoices to City in the manner specified herein.
Except as specifically authorized by City, Artist shall not bill City for duplicate services performed by more than one
person.
Artist and City acknowledge and agree that compensation paid by City to Artist under this Agreement is based upon
Artist's estimated costs of providing the services required hereunder, including salaries and benefits of employees
and subcontractors of Artist. Consequently, the parties further agree that compensation hereunder is intended to
include the costs of contributions to any pensions and/or annuities to which Artist and its employees, agents, and
subcontractors may be eligible. City therefore has no responsibility for such contributions beyond compensation
required under this Agreement.
Public Art Agreement between the April 17, 2018
City of Dublin and Sculptural Solutions Inc. Page 2 of 18
3.1 Invoices. Artist shall submit invoices as specified'in Exhibit B and C, not more often than once a
month during the term of this Agreement, based on the cost for services performed and
reimbursable costs incurred prior to the invoice date. Invoices shall contain the following
information:
■ Serial identifications of each billable phase; i.e., Bill No. 1 Phase I for the first invoice, etc.;
■ The beginning and ending dates of the billing period;
■ A Task Summary containing the original contract amount, the amount of prior billings, the
total due this period, the balance available under the Agreement, the Artist's signature.
3.2 Total Payment. City shall pay for the services to be rendered by Artist pursuant to this
Agreement. City shall not pay any additional sum for any expense or cost whatsoever incurred by
Artist in rendering services pursuant to this Agreement. City shall make no payment for any extra,
further, or additional service pursuant to this Agreement.
In no event shall Artist submit any invoice for an amount in excess of the maximum amount of
compensation provided above either for a task or for the entire Agreement, unless the Agreement
is modified prior to the submission of such an invoice by a properly executed change order or
amendment,
3.3 Payment of Taxes. Artist is solely responsible for the payment of employment taxes incurred
under this Agreement and any similar federal or state taxes,
3.4 Payment upon Termination. In the event that the City or Artist terminates this Agreement
pursuant to Section 17, the City shall compensate the Artist for all outstanding costs and
reimbursable expenses incurred for work satisfactorily completed as of the date of written notice of
termination, Artist shall maintain adequate logs and timesheets in order to verify costs incurred to
that date.
Section 4. FACILITIES AND EQUIPMENT. Except as set forth herein, Artist shall, at its sole cost and
expense, provide all facilities and equipment that may be necessary to perform the services required by this
Agreement.
Section 5. RESPONSIBILITY OF THE ARTIST
5.1 The Artist agrees that an essential element of this Agreement is the skill and creativity of the Artist.
The Artist shall not assign the creative or artistic portions of the Work to another party for the
production of the Work without the written consent of the City. Failure to conform to this provision
may be cause for termination of this Agreement, at the sole option of the City.
5.2 The Artist shall be responsible for providing services described in Exhibit B, including but not
limited to, the quality and timely completion of the services. As part of the Work, Artist shall be
responsible for designing the artwork, as described in Exhibit A, so that it can be constructed
without exceeding the approved overall budget for the artwork of $500,000.00. The Artist shall,
without additional compensation, correct or revise any errors, omissions, or other deficiencies in
his /her Work.
5.3 The Artist shall complete the fabrication and installation of the Work in substantial conformity with
the attached Exhibit B, Scope of Work.
Public Art Agreement between the April 17, 2018
City of Dublin and Sculptural Solutions Inc. Page 3 of 18
5.4 The risk of loss or damage to the Work shall be borne by the Artist until final acceptance by City.
The Artist shall take such measures as are necessary to protect the Work from loss or damage
until final acceptance by City.
Section 6. TIMELY PROVISION OF SERICES• DAMAGES FOR DELAYED PERFORMANCE: The parties
agree that in the performance of the terms and requirements of this Agreement by the Artist that time is of the
essence. Artist shall devote such time to the performance of services pursuant to this Agreement as may be
reasonably necessary for satisfactory performance of Artist's obligations pursuant to this Agreement.
6.1 Damages for Delayed Performance. Subject to reasonable proof and documentation confirming
the same submitted by the City, Artist shall be liable for all incidental and consequential damages
resulting, directly or indirectly, from delays in performance caused by Artist's acts or omissions,
Damages may include; but are not limited to the cost to retrofit the Work installation area should
Artist not meet installation schedule as specified in Exhibit B. The Artist shall not be liable to City
for damages resulting from delays caused by force majeure or by acts or omissions of City,
Architect or the General Contractor; or third party vandalism, except to the extent Artist failed
reasonably to mitigate such damages.
6.2 Illness, Injury, Death or Incapacity. Should Artist die, become ill, injured or otherwise
incapacitated (collectively, "incapacitated ") such that Artist is unable to work for any period not
exceeding 30 days (whether consecutive or non - consecutive), any delay arising out of such
incapacity will be allowed by City whenever it is practicable to do so, considering the facts and
circumstances of the Work, the Project, the Architect, the General Contractor and the Client. City
may require Artist to provide medical certification of any claimed incapacity. In the event Artist is
incapacitated such that Artist is unable to work for a period exceeding a total of 30 days (whether
consecutive or nonconsecutive), City may, at its option, undertake to complete and install the Work
in Artist's absence, so long as the final Artwork is substantially similar to that designed by Artist. If
City undertakes to complete the Work, City shall give due consideration to Artist's suggestions, and
Artist may disclaim authorship of the Work. If City exercises its option to implement the Artwork in
Artist's absence, any compensation paid or payable to Artist shall be reduced by the costs and
expenditures of City in completion and installation of the Work. In case of incapacity exceeding 30
days, the following person shall be Artist's representative vis -a -vis the City for purposes of this
Section 6 unless otherwise directed in writing by the Artist:
Michael Talbot
Treetops
Elkstone
Longnor
Buxton
Derbyshire SK17 OLU
Phone: 011 -44- 1538- 300208
Email: m.talbot @fsmail.com
Section 7. APPROVAL AND FINAL ACCEPTANCE OF ARTWORK. Payment does not imply acceptance of
work. The granting of any payment by City, or the receipt thereof by Artist, shall in no way lessen the liability of Artist
to replace unsatisfactory work, equipment, or materials, although the unsatisfactory character of such work,
equipment or materials may not have been apparent or detected at the time such payment was made, Materials,
equipment, components, or workmanship that does not conform to the requirements of this Agreement may be
rejected by City and in such case must be replaced by Artist without as soon as possible.
Public Art Agreement between the April 17, 2018
City of Dublin and Sculptural Solutions Inc. Page 4 of 18
7.1 The granting or withholding of any approval by the City shall be determined by the City in its sole
and reasonable discretion. However, the City shall approve all deliverables if they materially
conform to plans or, Contract Documents previously approved by the City. If the City withholds
approval of any deliverables or Phase, in addition to other rights or remedies available to the City
under the Agreement or applicable law, the City shall have the right to terminate this Agreement
immediately and shall have no further obligations under this Agreement.
7.2 Final Acceptance. Artist shall advise the City in writing when Artist has completed all obligations,
services and deliverables under this Agreement and all modifications. The City promptly shall send
a Notice of Response identifying in writing any obligations, services or deliverables that Artist has
not satisfactorily met, any defects in Artist's performance, and the requirements for Artist to cure
any such default. Artist shall have 20 days from dispatch of the Notice of Response to cure any
defects in Artist's performance identified in the City's Notice of Response. The Artwork shall not be
officially accepted by City unless the City has issued a resolution of Final Acceptance. City shall
make a good faith effort to make a determination as to Final Acceptance promptly.
7.3 Public Art Collection. Upon Final Acceptance, the City shall accession the Artwork into the Public
Art Collection,
Section B. WARRANTIES/STANDARDS
8.1 Unique. Artist warrants that the design of the Artwork as expressed in the Proposal, Exhibit A, is
an edition of one, and that neither Artist nor Artist's agents will execute or authorize another to
execute another work of the same or substantially similar image, design, dimensions and materials
as the Artwork. Artist may create works that utilize or incorporate various individual art elements
that comprise the Artwork, so long as the work utilizing or incorporating such individual elements
(1) does not consist predominantly of such elements, (2) is not the same or substantially similar in
image, design, dimensions and materials as the Artwork, and (3) is not displayed in an
environment that is the same or substantially similar to the environment in which the Artwork is to
be displayed at the site.
8.2 Warranty of Title. Artist represents and warrants that Artist is the sole author of the Artwork and
that Artist is the sole owner of any and all copyrights pertaining to the Artwork. Artist further
represents that the Artwork is free and clear of any liens and that there are no outstanding disputes
in connection with property rights, intellectual property rights or any other rights in the Artwork or
any parts of the Artwork.
8.3 - The Artist shall faithfully perform the work required under this Agreement in accordance with
standards of care, skill, training, diligence, and judgment provided by highly competent
professionals who perform work of a similar nature to the Work described in this Agreement. Artist
shall assign only competent personnel to perform services pursuant to this Agreement. In the event
that City, in its sole discretion, at any time during the term of this Agreement, desires the removal
of any such persons, Artist shall, immediately upon receiving notice from City of such desire of
City, cause the removal of such person or persons, unless in the Artist's sole opinion, the skill or
creativity of such person or persons is essential to the creation of the Work.
8.4 Warranty of Workmanship. The Artist shall guarantee his /her Work to be free from faults of
material and workmanship for a period of one (1) year after installation and final acceptance by the
City. The Artist shall deliver the Work to the City free and clear of any liens from any source
Public Art Agreement between the April 17, 2018
City of Dublin and Sculptural Solutions Inc. Page 5 of 18
whatsoever. The foregoing guarantees shall apply only to the Work that is entirely that of the Artist
or persons responsible to the Artist, as installed, and shall not apply to materials or workmanship of
projects in which the Work of the Artist is integrated or combined, or to materials purchased,
acquired, or installed by a person or entity not responsible to the Artist.
8.5 Warranty of Public Safety. Artist represents and warrants that the Work will not pose a danger to
public health or safety in view of the possibility of misuse, if such misuse is in a manner that was
reasonably foreseeable at any time during the term of this Agreement.
8.6 Warranty of Acceptable Standard of Display and Operation. Artist represents and warrants
that;
8.6.1 Occasional or minimal cleaning and repair of the Artwork and any associated working
parts and /or equipment will maintain the Work within an acceptable standard of public
display;
8.6.2 Foreseeable exposure to the elements and general wear and tear will cause the Work to
experience only minor repairable damages and will not cause the Work to fall below an
acceptable standard of public display; and
8.6.3 With general routine cleaning and repair, and within the context of foreseeable exposure
to the elements and general wear and tear, the Work will not experience irreparable
conditions that do not fall within an acceptable standard of public display, including mold,
rust, fracturing, staining, chipping, tearing, abrading and peeling.
8.7 Manufacturer's Warranties. To the extent the Work incorporates products covered by a
manufacturer's warranty, Artist shall provide copies of such warranties to City.
Section 9. MAINTENANCE OF ARTWORK
9.1 Unless specifically provided in this Agreement, Artist shall not be responsible for ongoing
maintenance of the Artwork, after acceptance by the City.
9.2 Artist shall provide the City with a General Maintenance Plan for the Artwork, with a detailed
description of future anticipated maintenance requirements; a recommended maintenance
schedule; anticipated and required care and /or replacement/upgrade of any part of the Artwork and
associated moving parts or equipment including any staff time involved in displaying or, operating
artwork and the frequency of such staff involvement; and written instructions and manufacturer's
specifications for reasonably foreseeable maintenance and preservation activities relating to the
Artwork.
9.3 The Artwork shall be durable, taking into consideration that the installation site is an unsecured
public space that may be exposed to elements such as weather, temperature variation, and
considerable movement of people and equipment. Artist shall ensure that all maintenance
requirements will be reasonable in terms of time and expense.
9.4 Although City strives to maintain the Public Art Collection in good repair and condition, City is not
required by this Agreement to maintain the Artwork to any particular standard. City may determine
to allow the Artwork to deteriorate in accordance with the Artwork's temporary life span, if deemed
appropriate by City or if City lacks sufficient funds for required maintenance and/or conservation. If
Public Art Agreement between the April 17, 2018
City of Dublin and Sculptural Solutions Inc. Page 6 of 18
the Artwork suffers deterioration, City shall have sole discretion to determine whether to remove
the Artwork from display as a result of deterioration, whether to replace any portion of the Artwork
or translate any component into new media, or whether to maintain the Artwork on display despite
its deteriorated condition.
9.5 The anticipated life span of the Artwork is 200 years from the date of final acceptance by the City.
After that time, the City in its sole discretion may re- evaluate the Artwork to determine if it retains
its identity as a work of art and, if not, whether to take appropriate action, including the possibility of
destroying the Artwork. If the City determines that, through decay, vandalism or other forces, the
Artwork has lost its integrity to the point where it should be destroyed, the City shall first offer the
Artwork to Artist free of charge and in writing.
Section 10. ARTIST'S RIGHTS: CITY'S OWNERSHIP RIGHTS
10.1 The City intends to display the Artwork as originally created by Artist in Exhibit A and to maintain
the Artwork in good condition. Public artworks commissioned by the City are sometimes integrated
into their site, such that they become an integral, permanent and site - specific part of the building's
architecture or landscaped environment and removal of the artwork would result in significant
changes to the artwork and the building's architecture. City, however, shall preserve complete
flexibility to operate and manage City property in the public's interest. Therefore, City retains the
absolute right to alter the Artwork in City's sole judgment. For example, City may alter the Artwork
to eliminate hazard, to comply with the ADA, to otherwise aid City in the management of its
property and affairs, or through neglect or accident. If, during or after the term of this Agreement,
City finds the Site to be inappropriate, City has the right to install the Artwork at an alternate
location that City chooses in its sole discretion. If the Artwork is free - standing such that it can be
removed without significant damage to the Artwork or the Site, and if the City authorizes the
removal of the Artwork, the City shall take reasonable precautions to minimize alteration of the
Artwork during removal.
10.2 With respect to the Artwork produced under this Agreement, and in consideration of the procedures
and remedies specified in this Agreement, Artist waives any and all claims, arising at any time and
under any circumstances, against City, its officers, agents, employees, successors and assigns,
arising under the federal Visual Artists Rights Act (and 113(d)), the California Art Preservation Act
(Cal. Civil Code § §987 et seq.), and any other local, state, federal or international laws that convey
rights of the same nature as those conveyed under 17 U.S.C. §106A, Cal. Civil Code § §987 et
seq., or any other type of moral right protecting the integrity of works of art If the Artwork is
incorporated into a building such that the Artwork cannot be removed from the building without
alteration of the Artwork, Artist waives any and all such claims against any future owners of the
site, and its agents, officers and employees, for alteration of the Artwork.
10.3 If City intends to take any action with respect to the site or the Artwork that would alter the Artwork,
other than routine cleaning and maintenance, the following procedures shall apply:
10.3.1 Notice. Where time permits, City shall make reasonable good faith efforts to notify Artist
at least 20 calendar days prior to authorizing any alteration of the Artwork, at the last
phone number or address provided by Artist to the City's Contract Administrator. Where
time does not permit prior to alteration of the Artwork — for example, in cases of public
hazard, accident or unauthorized alteration — City shall notify Artist within 30 calendar
days after such alteration.
Public Art Agreement between the April 17, 2018
City of Dublin and Sculptural Solutions Inc. Page 7 of 18
10.3.2 Consultation. After receiving such notice, Artist shall consult with City to determine
whether the Artwork can be restored or relocated, and to attempt to come to a mutually
agreeable plan for disposition of the Artwork. Such consultation shall be without charge by
Artist unless otherwise specifically agreed in writing. If City intends to remove the Artwork,
Artist shall consult regarding methods to minimize or repair any Alteration to the Artwork
caused by such removal and the potential costs of such removal.
10.3.3 Restoration. If the Artwork is altered, with or without prior notice to Artist, and City intends
to maintain the Artwork on display, City shall make a reasonable good faith effort to
engage Artist in the restoration of the Artwork and to compensate Artist for Artist's time
and efforts at fair market value, which may be the subject of a future Agreement between
Artist and City. However, City has no obligation under this Agreement to restore the
Artwork to its original condition, to compensate Artist for any restoration work, or to
maintain the Artwork on display. If Artist fails or refuses to negotiate with City in good faith
with respect to any restoration, City may contract with any other qualified art conservator
or artist for such restoration, During Artist's lifetime, City shall make best efforts not to
display or de- accession only a portion of the Artwork without Artist's consent.
10.3.4 Removal by Artist. Where time permits, if City intends to take action that will destroy or
significantly alter the Artwork, such as destruction of all or part of the site, and City
determines that it will not remove the Artwork itself, City shall allow Artist to remove the
Artwork at Artist's expense within 60 days of notice from the City of the need to remove
the Artwork, in which case title shall revert to Artist. If Artist fails to remove the Artwork
within that 60 day period, City may alter the Artwork in any manner, including destroying
it, in City's sole discretion.
10.3.5 Remedies. If City breaches any of its obligations under this Section, Artist's remedies
shall be limited as follows: If City inadvertently fails to provide a required prior notice of
alteration, City will provide notice as soon as it discovers the omission, and before
alteration of the Artwork if that remains possible. If City alters the Artwork without
providing Artist a required prior notice of alteration, Artist shall be given the first right of
refusal to restore the Artwork at the same location and City shall make reasonable efforts
to provide funding for the restoration. If City funds cannot be made available after
reasonable efforts are made to secure such funding, Artist may, but is not obligated to,
restore the Artwork at Artist's expense. If Artist elects not to restore the Artwork, City may
retain another artist or conservator to restore it, or may Alter the Artwork in any manner, at
City's sole discretion.
10.4 If City alters the Artwork without Artist's consent in a manner that is prejudicial to Artist's reputation,
Artist retains the right to disclaim authorship of the Artwork in accordance with California Civil Code
§987(4) and 17 U.S.C. §106A(a)(2).
10.5 Except as provided in this Agreement, with respect to third parties who are not officers, employees,
agents, successors or assigns of City, Artist retains Artist's moral rights in the Artwork, as
established in the Visual Artists Rights Act (17 U.S.C. § §106A and 113(4)), the California Art
Preservation Act (Cal. Civil Code § §987 and 989), or any other local, state, federal or international
moral rights laws that protect the integrity of works of art. Accordingly, nothing herein shall prevent
Artist from pursuing a claim for alteration of the Artwork against a third party who is not an officer,
employee, agent, successor or assign of City. City has no obligation to pursue claims against third
parties to remedy or prevent alteration of the Artwork. However, as owner of the Artwork, City may
Public Art Agreement between the April 17, 2018
City of Dublin and Sculptural Solutions Inc. Page 8 of 18
pursue claims against third parties for damages or to restore the Artwork if the Artwork has been
altered without City's authorization.
Section 11. INTELLECTUAL PROPERTY AND PUBLICITY RIGHTS
11.1 Copyright, Subject to usage rights and licenses granted to City hereunder, Artist shall retain all 17
U.S.C. §106 copyrights in all original works of authorship produced under this Agreement. Artist's
copyright shall not extend to predominantly utilitarian aspects of the Work, such as landscaping
elements, furnishings, or other similar objects. If Artist is comprised of two or more individual
persons, the individual persons shall be deemed joint authors of the Work.
11.2 . City's Intellectual Property License. Artist grants to City, and to City's agents, authorized
contractors and assigns, an unlimited, non - exclusive and irrevocable license to do the following
with respect to the Work, the Artwork, and any original works of authorship created under this
Agreement, whether in whole or in part, in all media (including electronic and digital) throughout the
universe:
11.2.1 Implementation, Use and Display. City may use and display the Work (to the extent the
Work includes graphic representations or models) and the Artwork. To the extent the
Work involves design elements that are incorporated by City into the design of the site,
City may implement such elements at the site,
11.2.2 Reproduction and Distribution. City may make and distribute, and authorize the
making, display and distribution of, photographs and other 2- dimensional reproductions.
City may use such reproductions for any City - related purpose, including advertising,
educational and promotional materials, brochures, books, flyers, postcards, print,
broadcast, film, electronic and multimedia publicity, gifts for City benefactors,
documentation of City's Public Art Collection, and catalogues or similar publications, City
shall ensure that such reproductions are made in a professional and tasteful manner, in
the sole and reasonable judgment of the City. The proceeds from the sale of any such
reproductions shall be used to maintain and support City's Public Art Collection or for any
other public purposes that City deems appropriate. The license granted hereunder
includes the right to create 2- dimensional reproductions on items such as tote -bags, T-
shirts, coffee mugs and similar merchandise. Nothing hereunder shall be construed to
constrain Artist from creating posters, note cards, or other reproductions of the Artwork
with appropriate credit to the City.
11.2.3 Public Records Requests. Any documents provided by Artist to City are public records
and City may authorize third parties to review and reproduce such documents pursuant to
public records laws, including the San Francisco Sunshine Ordinance and California
Public Records Act,
11.3 Third Party Infringement. The City is not responsible for any third party infringement of Artist's
copyright and not responsible for protecting the intellectual property rights of Artist.
11.4. Credit. All reproductions by the City shall contain a credit to the Artist and a copyright notice
substantially in the following form: "Steven Whyte(c), 2019." The Artist shall use his /her best efforts
to include a credit reading substantially "An original work commissioned by the City of Dublin,
California" in any public showing under the Artist's control of reproductions of the Work.
Public Art Agreement between the April 17, 2018
City of Dublin and Sculptural Solutions Inc. Page 9 of 18
11.5 Publicity. City shall have the right to use Artist's name, likeness, and biographical information, in
connection with the display or reproduction and distribution of the Artwork including all advertising
and promotional materials regarding City or the City. Artist shall be reasonably available to attend
any inauguration or presentation ceremonies relating to the public dedication of the Artwork.
11.6 Trademark. In the event that City's use of the Artwork creates trademark, service mark or trade
dress rights in connection with the Artwork, City shall have an exclusive and irrevocable right in
such trademark, service mark, or trade dress.
11.7 Resale Royalty. If City sells the Artwork as a fixture to real property, and if the resale value of the
Artwork is not itemized separately from the value of the real property, the parties agree that the
resale price of the Artwork shall be presumed to be less than the purchase price paid by City under
this Agreement. Thus, City has no obligation to pay resale royalties pursuant to California Civil
Code §986 or any other law requiring the payment of resale royalties. If City sells the Artwork as an
individual piece, separate from or itemized as part of a real property transaction, City shall pay to
Artist a resale royalty to the extent required by law, based upon the sale price of the Artwork.
11.8 If for any reason the proposed design is not implemented, all rights to the proposed artwork shall
be retained by the Artist. The City shall have no right to implement the proposed artwork, whether
or not protected by copyright, unless and until the City and the Artist enter into a subsequent
agreement for the implementation of the proposed design.
Section 12. OWNERSHIP OF RESULTS AND RISK OF LOSS
12.1 Title Transfer. Except in the case of early termination of this Agreement, title to the Artwork shall
transfer from Artist to City upon the City's Final Acceptance of the Artwork. Title transfer shall be
self- executing upon City's Final Acceptance. Artist will cooperate in providing to City any title
transfer documents City may request or require during or after the Term of this Agreement.
12.2 Risk of Loss. The risk of loss or damage to the Artwork shall be borne solely by Artist until Final
Acceptance of the Artwork by the City. Artist shall take steps to protect the Artwork from loss or
damage. The City staff shall make a good faith effort to inspect the Artwork within 15 days after
completion so that the City can approve the Artwork by resolution in a timely fashion.
12.3 Ownership of Documents. Conceptual Design; Design Development Documents, Construction
Documents, Samples, Mock -ups and all other documents prepared and submitted by Artist to the
City pursuant to this Agreement shall belong to the City. Artist may retain originals of such
documents and items and provide copies to City.
Section 13. INSURANCE REQUIREMENTS. Before beginning any work under this Agreement, Artist, at its
own cost and expense, shall procure "occurrence coverage" insurance against claims for injuries to persons or
damages to property that may arise from or in connection with the performance of the work hereunder by the Artist
and its agents, representatives, employees, and subcontractors. Artist shall provide proof satisfactory to City of such
insurance that meets the requirements of this section and under forms of insurance satisfactory in all respects to the
City. Artist shall maintain the insurance policies required by this section throughout the term of this Agreement. The
cost of such insurance shall be included in the Artist's bid. Artist shall not allow any subcontractor to commence work
on any subcontract until Artist has obtained all insurance required herein for the subcontractor(s) and provided
evidence thereof to City. Verification of the required insurance shall be submitted and made part of this Agreement
prior to execution.
Public Art Agreement between the April 17, 2018
City of Dublin and Sculptural Solutions Inc. Page 10 of 18
13.2 Commercial General and Automobile Liability Insurance.
13.2.1 General requirements. Artist, at its own cost and expense, shall maintain commercial
general and automobile liability insurance for the term of this Agreement in an amount not
less than ONE MILLION DOLLARS .($1,000,000,00) per occurrence, TWO MILLION
DOLLARS ($2,000,000.00) aggregate, combined single limit coverage for risks associated
with the work contemplated by this Agreement. If a Commercial General Liability
Insurance or an Automobile Liability form or other form with a general aggregate limit is
used, either the general aggregate limit shall apply separately to the work to be performed
under this Agreement or the general aggregate limit shall be at least twice the required
occurrence limit. Such coverage shall include but shall not be limited to, protection
against claims arising from bodily and personal injury, including death resulting therefrom,
and damage to property resulting from activities contemplated under this Agreement,
including the use of owned and non -owned automobiles.
13.2.2 Minimum scope of coverage. Commercial general coverage shall be at least as broad
as Insurance Services Office Commercial General Liability occurrence form CG 0001 (ed.
11/88) or Insurance Services Office form number GL 0002 (ed. 1/73) covering
comprehensive General Liability and Insurance Services Office form number GL 0404
covering Broad Form Comprehensive General Liability. Automobile coverage shall be at
least as broad as Insurance Services Office Automobile Liability form CA 0001 (ed. 12/90)
Code 8 and 9 ( "any auto "). No endorsement shall be attached limiting the coverage.
13.2.3 Additional requirements. Each of the following shall be included in the insurance
coverage or added as an endorsement to the policy:
City and its officers, employees, agents, and volunteers shall be covered as
additional insureds with respect to each of the following: liability arising out of
activities performed by or on behalf of Artist, including the insured's general
supervision of Artist; products and completed operations of Artist; premises
owned, occupied, or used by Artist; and automobiles owned, leased, or used by
the Artist. The coverage shall contain no special limitations on the scope of
protection afforded to City or its officers, employees, agents, or volunteers.
b. The insurance shall cover on an occurrence or an accident basis, and not on a
claims -made basis.
C. An endorsement must state that coverage is primary insurance with respect to
the City and its officers, officials, employees and volunteers, and that no
insurance or self- insurance maintained by the City shall be called upon to
contribute to a loss under the coverage.
Any failure of Artist to comply with reporting provisions of the policy shall not
affect coverage provided to City and its officers, employees, agents, and
volunteers.
e. An endorsement shall state that coverage shall not be canceled except after
thirty (30) days' prior written notice by certified mail, return receipt requested, has
been given to the City. Artist shall notify City within 14 days of notification from
Public Art Agreement between the April 17, 2018
City of Dublin and Sculptural Solutions Inc. Page 11 of 18
Artist's insurer if such coverage is suspended, voided or reduced in coverage or
in limits.
13.3 All Policies Requirements.
13.3.1 Acceptability of insurers. All insurance required by this section is to be placed with
insurers with a Bests' rating of no less than ANIL
13.3.2 Verification of coverage. Prior to beginning any work under this Agreement, Artist shall
furnish City with certificates of insurance and with original endorsements effecting
coverage required herein. The certificates and endorsements for each insurance policy
are to be signed by a person authorized by that insurer to bind coverage on its behalf.
The City reserves the right to require complete, certified copies of all required insurance
policies, at any time.
13.3.3 Subcontractors. Artist shall include all subcontractors as insureds under its policies or
shall furnish separate certificates and endorsements for each subcontractor, All
coverages for subcontractors shall be subject to all of the requirements stated herein.
13.3.4 Variation. The City may approve a variation in the foregoing insurance requirements,
upon a determination that the coverages, scope, limits, and forms of such insurance are
either not commercially available, or that the City's interests are otherwise fully protected.
13.3.5 Deductibles and Self- Insured Retentions. Artist shall disclose to and obtain the
approval of City for the self- insured retentions and deductibles before beginning any of the
services or work called for by any term of this Agreement,
During the period covered by this Agreement, only upon the prior express written
authorization of Contract Administrator, Artist may increase such deductibles or self -
insured retentions with respect to City, its officers, employees, agents, and volunteers.
The Contract Administrator may condition approval of an increase in deductible or self -
insured retention levels with a requirement that Artist procure a bond, guaranteeing
payment of losses and related investigations, claim administration, and defense expenses
that is satisfactory in all respects to each of them.
13.3.6 Notice of Reduction in Coverage. In the event that any coverage required by this
section is reduced, limited, or materially affected in any other manner, Artist shall provide
written notice to City at Artist's earliest possible opportunity and in no case later than five
days after Artist is notified of the change in coverage.
13.4 Remedies. In addition to any other remedies City may have if Artist fails to provide or maintain
any insurance policies or policy endorsements to the extent and within the time herein required,
City may, at its sole option exercise any of the following remedies, which are alternatives to other
remedies City may have and are not the exclusive remedy for Artist's breach:
Obtain such insurance and deduct and retain the amount of the premiums for such insurance
from any sums due under the Agreement;
Public Art Agreement between the April 17, 2018
City of Dublin and Sculptural Solutions Inc. Page 12 of 18
■ Order Artist to stop work under this Agreement or withhold any payment that becomes due to
Artist hereunder, or both stop work and withhold any payment, until Artist demonstrates
compliance with the requirements hereof; and /or
■ Terminate this Agreement.
Section 14. INDEMNIFICATION AND ARTIST'S RESPONSIBILITIES. Artist shall indemnify, defend with
counsel mutually selected by the City and Artist, and hold harmless the City and its officials, officers, employees,
agents, and volunteers from and against any and all losses, liability, claims, suits, actions, damages, and causes of
action arising out of any personal injury, bodily injury, loss of life, or damage to property, or any violation of any
federal, state, or municipal law or ordinance, to the extent caused, in whole or in part, by the willful misconduct or
negligent acts or omissions of Artist or its employees, subcontractors, or agents, by acts for which they could be held
strictly liable, or by the quality or character of their work, The foregoing obligation of Artist shall not apply when (1)
the injury, loss of life, damage to property, or violation of law arises wholly from the negligence or willful misconduct
of the City or its officers, employees, agents, or volunteers and (2) the actions of Artist or its employees,
subcontractor, or agents have contributed in no part to the injury, loss of life, damage to property, or violation of law.
It is understood that the duty of Artist to indemnify and hold harmless includes the duty to defend as set forth in
Section 2778 of the California Civil Code. Acceptance by City of insurance certificates and endorsements required
under this Agreement does not relieve Artist from liability under this indemnification and hold harmless clause. This
indemnification and hold harmless clause shall apply to any damages or claims for damages whether or not such
insurance policies shall have been determined to apply. By execution of this Agreement, Artist acknowledges and
agrees to the provisions of this Section and that it is a material element of consideration.
In the event that Artist or any employee, agent, or subcontractor of Artist providing services under this Agreement is
determined by a court of competent jurisdiction or the California Public Employees Retirement System (PERS) to be
eligible for enrollment in PERS as an employee of City, Artist shall indemnify, defend, and hold harmless City for the
payment of any employee and /or employer contributions for PERS benefits on behalf of Artist or its employees,
agents, or subcontractors, as well as for the payment of any penalties and interest on such contributions, which
would otherwise be the responsibility of City.
Section 15. STATUS OF ARTIST AS INDEPENDENT CONTRACTOR.
15.1 Independent Contractor. At all times during the term of this Agreement, Artist shall be an
independent contractor and shall not be an employee of City. City shall have the right to control
Artist only insofar as the results of Artist's services rendered pursuant to this Agreement and
assignment of personnel pursuant to Subparagraph 1.3; however, otherwise City shall not have the
right to control the means by which Artist accomplishes services rendered pursuant to this
Agreement. Notwithstanding any other City, state, or federal policy, rule, regulation, law, or
ordinance to the contrary, Artist and any of its employees, agents, and subcontractors providing
services under this Agreement shall not qualify for or become entitled to, and hereby agree to
waive any and all claims to, any compensation, benefit, or any incident of employment by City,
including but not limited to eligibility to enroll in the California Public Employees Retirement System
(PERS) as an employee of City and entitlement to any contribution to be paid by City for employer
contributions and /or employee contributions for PERS benefits.
15.2 Nothing contained in this Agreement shall be construed as limiting the right of Artist to engage in
his /her profession separate and apart from this Agreement so long as such activities do not
interfere with the performance by Artist of his/her obligations as set forth in this Agreement,
Public Art Agreement between the April 17, 2018
City of Dublin and Sculptural Solutions Inc. Page 13 of 18
15.3 Artist No Agent. Except as City may specify in writing, Artist shall have no authority, express or
implied, to act on behalf of City in any capacity whatsoever as an agent. Artist shall have no
authority, express or implied, pursuant to this Agreement to bind City to any obligation whatsoever.
Section 16. LEGAL REQUIREMENTS.
16.1 Governinq Law. The laws of the State of California shall govern this Agreement.
16.2 Compliance with Applicable Laws. Artist and any subcontractors shall comply with all laws
applicable to the performance of the work hereunder,
16.3 Other Governmental Regulations. To the extent that this Agreement may be funded by fiscal
assistance from another governmental entity, Artist and any subcontractors shall comply with all
applicable rules and regulations to which City is bound by the terms of such fiscal assistance
program.
16.4 Licenses and Permits. Artist represents and warrants to City that Artist and its employees,
agents, and any subcontractors have all licenses, permits, qualifications, and approvals of
whatsoever nature that are legally required to practice their respective professions. Artist
represents and warrants to City that Artist and its employees, agents, any subcontractors shall, at
their sole cost and expense, keep in effect at all times during the term of this Agreement any
licenses, permits, and approvals that are legally required td practice their respective professions.
In addition to the foregoing, Artist and any subcontractors shall obtain and maintain during the term
of this Agreement valid Business Licenses from City,
16.5 Nondiscrimination and Equal Opportunity. Artist shall not discriminate, on the basis of a
person's race, religion, color, national origin, age, physical or mental handicap or disability, medical
condition, marital status, sex, or sexual orientation, against any employee, applicant for
employment, subcontractor, bidder for a subcontract, or participant in, recipient of, or applicant for
any services or programs provided by Artist under this Agreement. Artist shall comply with all
applicable federal, state, and local laws, policies, rules, and requirements related to equal
opportunity and nondiscrimination in employment, contracting, and the provision of any services
that are the subject of this Agreement, including but not limited to the satisfaction of any positive
obligations required of Artist thereby.
Section 17. TERMINATION AND MODIFICATION.
17.1 , Termination. City may cancel this Agreement at any time and without cause upon written
notification to Artist.
Artist may cancel this Agreement upon thirty (30) days' written notice to City and shall include in
such notice the reasons for cancellation.
In the event of termination, Artist shall be entitled to compensation for services performed to the
effective date of termination; City, however, may condition payment of such compensation upon
Artist delivering to City any or all documents, photographs, computer software, video and audio
tapes, and other materials provided to Artist or prepared by or for Artist or the City in connection
with this Agreement.
Public Art Agreement between the April 17, 2018
City of Dublin and Sculptural Solutions Inc. Page 14 of 18
17.2 Extension. City may, in its sole and exclusive discretion, extend the end date of this Agreement
beyond that provided for in Subsection 1.1. Any such extension shall require a written amendment
to this Agreement, as provided for herein. Artist understands and agrees that, if City grants such
an extension, City shall have no obligation to provide Artist with compensation beyond the
maximum amount provided for in this Agreement. Similarly, unless authorized by the Contract
Administrator, City shall have no obligation to reimburse Artist for any otherwise reimbursable
expenses incurred during the extension period.
17.3 Amendments. The parties may amend this Agreement only by a writing signed by all the parties.
17.4 Assignment and Subcontracting. City and Artist recognize and agree that this Agreement
contemplates personal performance by Artist and is based upon a determination of Artist's unique
personal competence, experience, and specialized personal knowledge. Moreover, a substantial
inducement to City for entering into this Agreement was and is the professional reputation and
competence of Artist. Artist may not assign this Agreement or any interest therein without the prior
written approval of the Contract Administrator. Artist shall not subcontract any portion of the
performance contemplated and provided for herein, other than to the subcontractors noted in the
proposal, without prior written approval of the Contract Administrator.
17.5 Survival. All obligations arising prior to the termination of this Agreement and all provisions of this
Agreement allocating liability between City and Artist shall survive the termination of this
Agreement.
17.6 Options upon Breach by Artist. If Artist materially breaches any of the terms of this Agreement,
City's remedies shall include, but not be limited to, the following:
17.6.1 Immediately terminate the Agreement;
17.6.2 Retain the plans, specifications, drawings, reports, design documents, and any other work
product prepared by Artist pursuant to this Agreement;
17.6.3 Retain a different Artist to complete the work described in Exhibit A not finished by Artist;
or
17.6.4 Charge Artist the difference between the cost to complete the work described in Exhibit A
that is unfinished at the time of breach and the amount that City would have paid Artist
pursuant to Section 2 if Artist had completed the work.
Section 18. KEEPING AND STATUS OF RECORDS.
18.1 City Access to Artwork; Inspection of Work and Artwork. City shall have the reasonable right
to, at its sole expense, inspect the Work, including the Artwork, at the fabrication Site during any
phase of the project at any time. In the event that all or part of the Work is created in a location
other than the Site, the City shall have the right to inspect the Work, including the Artwork, at any
phase of the project following 48 hours written notice from the City to the Artist. The Artist shall be
responsible for facilitating City's prompt access to Artist's property or the property of the Artist's
subcontractors where the Work or portions of the Work are being fabricated or installed.
18.2 Status Reports. Artist shall submit written reports regarding the status of the Work, including the
Artwork, as may be reasonably requested by the City. The City shall determine the format for the
Public Art Agreement between the April 17, 2018
City of Dublin and Sculptural Solutions Inc. Page 15 of 18
content of such reports. The timely submission of all reports is a necessary and material term and
condition of this Agreement. The reports, including any copies, shall be submitted on recycled
paper and printed on double -sided pages to the maximum extent possible.
18.3 Artist Availability. Artist or Artist's authorized agent shall be available at Artist's sole expense for
up to 2 visits to Dublin to ensure the proper installation and operation of the Artwork. During each
visit to Dublin, unless otherwise agreed upon by the City, the Artist's visit shall last for at least a full
8 hour day.
18.4 Records Created as Part of Artist's Performance. With the exception of model submitted with
initial proposal, all reports, data, maps, models, charts, studies, surveys, photographs,
memoranda, plans, studies, specifications, records, files, or any other documents or materials, in
electronic or any other form, that Artist prepares or obtains pursuant to this Agreement and that
relate to the matters covered hereunder shall be the property of the City. Artist hereby agrees to
deliver those documents to the City upon termination of the Agreement. It is understood and
agreed that the documents and other materials, including but not limited to those described above,
prepared pursuant to this Agreement are prepared specifically for the City and are not necessarily
suitable for any future or other use. City and Artist agree that, until final approval by City, all data,
plans, specifications, reports and other documents are confidential and will not be released to third
parties without prior written consent of both parties. It is also agreed that proposal model remains
property of the Artist and will be returned to Artist after the finished sculpture is installed.
18.5 Artist's Books and Records. Artist shall maintain any and all ledgers, books of account, invoices,
vouchers, canceled checks, and other records or documents evidencing or relating to charges for
services or expenditures and disbursements charged to the City under this Agreement for a
minimum of three (3) years, or for any longer period required by law, from the date of final payment
to the Artist to this Agreement.
18.6 Inspection and Audit of Records. Any records or documents that Section 9.2 of this Agreement
requires Artist to maintain shall be made available for inspection, audit, and/or copying at any time
during regular business hours, upon oral or written request of the City, Under California
Government Code Section 8546.7, if the amount of public funds expended under this Agreement
exceeds TEN THOUSAND DOLLARS ($10,000.00), the Agreement shall be subject to the
examination and audit of the State Auditor, at the request of City or as part of any audit of the City,
for a period of three (3) years after final payment under the Agreement.
Section 19. MISCELLANEOUS PROVISIONS.
19.1 Attorneys' Fees. If a party to this Agreement brings any action, including an action for declaratory
relief, to enforce or interpret the provision of this Agreement, the prevailing party shall be entitled to
reasonable attorneys' fees in addition to any other relief to which that party may be entitled. The
court may set such fees in the same action or in a separate action brought for that purpose.
19.2 Venue. In the event that either party brings any action against the other under this Agreement, the
parties agree that trial of such action shall be vested exclusively in the state courts of California in
the County of Alameda.
19.3 Severability. If a court of competent jurisdiction finds or rules that any provision of this Agreement
is invalid, void, or unenforceable, the provisions of this Agreement not so adjudged shall remain in
Public Art Agreement between the April 17, 2018
City of Dublin and Sculptural Solutions Inc. Page 16 of 18
full force and effect. The invalidity in whole or in part of any provision of this Agreement shall not
void or affect the validity of any other provision of this Agreement,
19.4 No Implied Waiver of Breach. The waiver of any breach of a specific provision of this Agreement
does not constitute a waiver of any other breach of that term or any other term of this Agreement.
19.5 Successors and Assigns. The provisions of this Agreement shall inure to the benefit of and shall
apply to and bind the successors and assigns of the parties.
19.6 Use of Recycled Products. Artist shall prepare and submit all reports, written studies and other
printed material on recycled paper to the extent it is available at equal or less cost than virgin
paper.
19.7 Conflict of Interest. Artist may serve other clients, but none whose activities within the corporate
limits of City or whose business, regardless of location, would place Artist in a "conflict of interest,"
as that term is defined in the Political Reform Act, codified at California Government Code Section
81000 et seq.
Artist shall not employ any City official in the work performed pursuant to this Agreement. No
officer or employee of City shall have any financial interest in this Agreement that would violate
California Government Code Sections 1090 et seq.
Artist hereby warrants that it is not now, nor has it been in the previous twelve (12) months, an
employee, agent, appointee, or official of the City. If Artist was an employee, agent, appointee, or
official of the City in the previous twelve months, Artist warrants that it did not participate in any
manner in the forming of this Agreement. Artist understands that, if this Agreement is made in
violation of Government Code §1090 et.seq., the entire Agreement is void and Artist will not be
entitled to any compensation for services performed pursuant to this Agreement, including
reimbursement of expenses, and Artist will be required to reimburse the City for any sums paid to
the Artist. Artist understands that, in addition to the foregoing, it may be subject to criminal
prosecution for a violation of Government Code § 1090 and, if applicable, will be disqualified from
holding public office in the State of California.
19.8 Solicitation. Artist agrees not to solicit business at any meeting, focus group, or interview related
to this Agreement, either orally or through any written materials.
19.9 Contract Administration. This Agreement shall be administered by the City Manager or his/her
designee ( "Contract Administrator "). All correspondence shall be directed to or through the
Contract Administrator or his or her designee,
19.10 Notices. Any written notice to Artist shall be sent to;
Steven Whyte, President
Sculptural Solutions Inc.
P.O. Box 148
Carmel, CA 93921
831 - 620 -1917
sw@stevenwhytestudios.com
www.stevenwhytestudios.com
Public Art Agreement between the April 17, 2018
City of Dublin and Sculptural Solutions Inc. Page 17 of 18
Any written notice to City shall be sent to:
City Manager
City of Dublin
100 Civic Plaza
Dublin, CA 94568
(925) 833 -6645
19.11 Professional Seal. Where applicable in the determination of the contract administrator, the first
page of a technical report, first page of design specifications, and each page of construction
drawings shall be stamped /sealed and signed by the licensed professional responsible for the
report/design preparation. The stamp /seal shall be in a block entitled "Seal and Signature of
Registered Professional with report /design responsibility," as in the following example.
Seal and Signature of Registered Professional with
report/design responsibility,
19.12 Integration. This Agreement, including the proposal, scope of work, and payment schedule
attached hereto and incorporated herein as Exhibits A, B and C, represents the entire and
integrated agreement between City and Artist and supersedes all prior negotiations,
representations, or agreements, either written or oral.
CITY OF DUBLIN
Chris Foss, City Manager
Attest:
Caroline Soto, City Clerk
Approved as to Form:
John Bakker, City Attorney
2950394.1
ARTIST
Steven Whyte, President
Sculptural Solutions Inc.
Public Art Agreement between the April 17, 2018
City of Dublin and Sculptural Solutions Inc. Page 18 of 18
EXHIBIT A
PROPOSAL
Attached is Artist's Proposal at the time of the Agreement date.
"Proposal" shall mean the proposed visual, aesthetic, and artistic intent and design of the Artwork
incorporated in the Contract Documents approved by the Dublin City Council. The most recent
design approved by the Dublin City Council is incorporated herein by reference, and is binding
unless or until changes are approved by resolution of the Dublin City Council.
Artist's Proposal shall be automatically superseded by any Contract Documents that are later
approved by the City Council.
Artist's proposal will be developed, fabricated and installed in accordance with Exhibit B: Scope of
Work.
Design Concept 2: Crossroads
In considering a veterans' memorial for the City of Dublin, Steven Whyte Sculpture Studios is
committed to creating a unique piece of public art that celebrates servicemen and women and the city
of Dublin itself.
Inspirational and uplifting, Whyte's concept is designed to be authentic, reverent and engaging while
featuring clear details specific to Camp Parks' past and future heroes.
The footprint of the monument will be constructed from granite pavers measuring 26 feet square.
Dissecting the plaza are two roads creating a crossroads that echoes Dublin's history as a destination
for two intersecting stagecoach routes. Constructed in concrete, the two roads are sculpted with a
variety of textures to indicate everything from evolving jeep tire treads to a large variety of footprints
representing the many varieties of servicemen and women who have left their mark on Camp Parks
and Dublin. These elements allow for public participation and engagement, encouraging visitors to
walk in the footsteps of these heroes. The two roads are also designed to symbolize the universal
journey of military service and the long path that begins with enlistment and travels through training,
deployment and the eventual return to civilian life.
Standing at the four corners of the intersection are four 9 foot tall figures of veterans standing at
attention in front of flags erected at each junction. These lit flagpoles would be the tallest element of
the design measuring 25 feet high. The flags would feature an American flag, the flag for the state of
California and the flag for the City of Dublin. The fourth flag pole would allow for rotating
representation and could be switched out for ceremonial events.
Each figure represents a military branch and time period significant to Camp Parks. Steven Whyte
Sculpture studios would work with the committee and Camp Parks to determine the best subjects for
these figures and ensure the authenticity of each detail. Based on discussion with local historians it has
been suggested that the figures represent the following military branches, genders and ethnicities: a
WWII Navy Sea Bea, this figure would be Caucasian and slightly older than a new recruit; an African -
American male member of the Korean Air Force; a Caucasian male marine from the Vietnam era; and
finally a Latina or Filipina representing a modern member of the Army reserves.
One of the most important elements of public work is the manner in which it allows for public
engagement. Figurative work is unique in its ability to strike an immediate connection with the public.
There would be no safety concerns and visitors would be encouraged to stand alongside the figures and
walk along the crossroads as well as follow the footprints of the servicemen and women who marched
on behalf of their country.
Materials for the monument are cast bronze, poured concrete and granite. These materials are
extremely durable to both age and weather and have a life expectancy of several hundred years at a
minimum. They also require very little maintenance. Recommended care would include washing down
once a year and waxing.
The monument would be cast at Art Works Foundry in Berkeley, California, one of the leading
foundries in the nation. Steven Whyte Sculptor Studios would complete all other work. Installation
would be relatively simple and would involve the following actions creating a concrete pad, laying
granite slabs, and installing the bronze. This work would be completed by the general contractor team
of Hathaway Dinwiddie under the supervision of Steven Whyte Studios. Very little special equipment
would be required, but the studio would engage the Bay Area firm Sheedy Drayage Company to
oversee the crane and rigging.
Steven Whyte Sculpture Studios is honored to be considered for this important project.
Design Concept: Crossroads
Veterans Memorial for the City of Dublin, Steven Whyte Sculpture Studios
Original version, seen by the Selection Committee and Commissions:
Revised figure selections, based following historical input and military protocol input:
EXHIBIT B
SCOPE OF WORK
SCHEDULE FOR COMPLETION OF WORK. The following fabrication schedule shall be adhered
to in the performance of the work. During the term of this Agreement, the City Project Manager
must approve Artist's work at each phase of development before the Artist proceeds to the next
phase. The City Project Manager for this Agreement is;
DELIVERABLES:
1, Fully Executed Contract
Tegan McLane
Heritage and Cultural Arts Manager
100 Civic Plaza
Dublin, CA 94568
(925) 556 -4565
tegan.mclane @dublin,ca.gov
DUE DATE:
May 17, 2018 (Est.)
2. Evidence of All Required Insurance, Dublin Business May 10, 2018
License
The scope of work under this phase includes research phase and completion of engineering
documents for the Artwork and Plaza.
• The Artist shall work with a California licensed engineer to provide the City with stamped
drawings for the Artwork and Plaza.
• Phase shall be considered complete when stamped engineering documents are received
by the City Project Manager. Payment may be released earlier than the date specified
should the Phase be deemed complete.
DELIVERABLES: DUE DATE:
1. Engineered Drawings
July 1, 2018
The scope of work under this phase includes completion of the clay models of the four Artwork
figures at 150% life size,
• Artist shall participate in in- person meetings, conference calls, etc. with Developer's Design
and Construction Team as needed to incorporate Artwork into the project construction
documents and park design,
• Artist shall coordinate his /her communications with the Developer through the City Project
Manager, copying the City Project Manager on all correspondence.
• Phase will be considered complete when all deliverables have been received by City Project
Manager. Payment may be released earlier than date specified should Phase be deemed
complete.
DELIVERABLES: DUE DATE:
1. Final Dimensional Design Documents for Integration June 1, 2018
with Construction Documents
2. Material Samples and /or Mock Ups as Requested by September 1, 2018 (Est.)
Design Team
3. Artist's Confirmation via e-mail that Architect's Design September 1, 2018 (Est.)
Development and /or Construction Documents
accurately. integrate of Artist's Proposal within the Site
and provide the City and Architect with written
comments and /or corrections.
4. Progress Report to indicate any potential change to September 1, 2018 (Est.)
project timeline.
5. Studio Tour for City Representatives to see and sign off September 30, 2018 (Est.)
on Clay Models of the four Artwork Figures. Following
the City's approval, there will be no changes to the
design without mutual consent of the Artist and the City.
The scope'of work under this phase includes delivery of the molds to the Foundry:
• Artist will complete the molds, according to the clay figures previously approved by the
City.
• Should artist wish to make changes during the wax process, Artist will obtain City's written
approval for any changes substantial enough to be visible to a layperson.
• Phase will be considered complete when all deliverables have been received by City
Project Manager: Payment may be released earlier than date specified should Phase be
deemed complete.
DELIVERABLES: DUE DATE:
1. Photos of the completed molds. December 1, 2018 (Est.)
2. Confirmation from the Foundry to the City that the molds December 10, 2018 (Est.)
have been received in good condition.
3. Progress Report to indicate any potential change to project December 10, 2018 (Est.)
timeline.
The scope of work under this phase includes casting of all bronze parts and concrete /electrical
work for the plaza, which is considered part of the Artwork:
Foundry will complete the bronze castings, according to the molds created in the previous
phase.
• The preparation of the Site for installation of the Artwork shall be the responsibility of the
Developer in accordance with a separate written agreement between City and the
Developer.
• Working in cooperation with the Developer, Artist's concrete and electrical subs will
complete those portions of the plaza considered part of the Artwork, in preparation for
installation of the bronze figures.
• Artist shall work cooperatively with the City to draft Artist Statement, which is to be
incorporated into the plaque installed at the site. The City requires that all signage to be
displayed on City property adhere to conventionally accepted spelling and punctuation,
proper grammar and City style preferences, as determined by the City of Dublin Public
Information Officer.
• Phase will be considered complete when all deliverables have been received by City
Project Manager. Payment may be released earlier than date specified should Phase be
deemed complete.
DELIVERABLES:
1. City approval of an Artist Vision Statement and signage
text.
2. Photos of all bronze parts, or sign -off of City Project
Manager's inspection of bronze castings at the Foundry.
3. City Project Manager's or Special Inspector's sign off on
concrete and electrical portions of the project.
4. Progress Report to indicate any potential change to project
timeline.
DUE DATE:
December 1, 2018 (Est.)
February 1, 2019 (Est.)
February 28, 2019 (Est.)
February 28, 2019 (Est.)
The scope of work under this phase includes the completion of the plaza elements and installation
of the figures and plaque and signage:
• Prior to transportation and installation of Artwork, Artist's structural engineer shall verify in
writing that the preparation of the artwork attachment or mounting system and installation
is being implemented in accordance with the signed stamped structural engineering
drawings.
• Artist shall prepare the Artwork for transportation in accordance with customary industry
standards for the transportation of fine works of art.
• If necessary, City shall provide Artist with an adequate no -fee storage location for the
Artwork. Storage will be at the Artist's risk and covered by his insurance.
• If necessary, Artist shall provide for the transportation of the Artwork from storage to the
installation site. Artist shall not transport the Artwork until access to the Site has been
approved and scheduled by the Contract Administrator.
• Artist shall create with the City Project Manager and Developer an installation plan
indicating the staging and sequence of all aspects of installation. The Installation Plan
must include a detailed description of the estimated duration of installation, the equipment
to be used, and all workers who will be on site to assist.
• Artist shall consult with the City, the Developer and General Contractor prior to and during
the installation of the Artwork.
• Artist shall coordinate Artist's activities on site with the Developer and General Contractor
through the Construction Management Team and /or the City staff.
• Artist shall supply all hardware necessary for installation.
• Where Artist's Artwork is associated with that of the General Contractor, or any other
Contractor engaged by the Developer to do work on the Site, Artist shall examine the
work of such other Contractor and report in writing to the City and Developer any visible
defect or condition preventing the proper execution of Artist's Work. Developer will provide
a finished pad and bring electrical to the site.
• If Artist proceeds without giving notice, the Artist shall be held to have approved the work
or material and the existing conditions, and shall be responsible for any defects in Artist's
own Work consequent thereon, and shall not be relieved of any obligation or any
guarantee because of any such condition or imperfection.
• To the extent that any part of the Artist's Artwork is to interface with work performed or
installed by the General Contractor or other Contractor engaged by Developer to perform
work on the Site, Artist shall inspect and measure the in -place work and promptly report to
the City and Developer any defect in such in -place work that will impede or increase the
cost of Artist's interface unless corrected.
• City and /or its authorized representatives will require the party responsible for the
defective work to make corrections so as to conform to its contract requirements, or if the
defect is the result of a default or omission in the contract documents, may issue a
change order.
• If Artist fails to measure, inspect and /or report defects that are reasonably discoverable,
all costs of accomplishing the interface shall be borne by Artist. The forgoing does not
apply to latent defects. Artist shall report to City any latent defects in another Contractor's
work at any time such defects become known.
• City or its authorized representatives shall promptly thereafter take such steps as may be
appropriate. Any difference or conflict that may arise between Artist and Developer,
General Contractor, or other Contractors engaged by City to perform work on the Site,
shall be adjusted as determined by City, its agents, or its authorized representatives when
necessary to facilitate the work of Artist and /or other Contractors or workers.
• No damages or claims by Artist will be allowed other than an extension of time for the
completion of Work. Such an extension will be for the period of time City shall consider
Artist to have been delayed in the completion of Work by reason of the work of other
Contractors or workers.
• Artist shall deliver all information necessary for the City to properly care for and maintain
the Artwork, including information regarding the physical make -up of the Artwork, methods
and materials, and information about the artistic intent of Artist in the Design, Fabrication
and Installation of the Artwork
• Phase will be considered complete when all deliverables have been received by City
Project Manager.
• Artist is invited, but not required, to attend artwork dedication in conjunction with the Park
opening event. Artist will be given at least three months' notice of the selected Park
Opening date. While every effort will be made to coordinate with the Artist's schedule, the
Park Opening event will not be rescheduled in the event that the Artist is unable to attend
on the selected date.
DELIVERABLES:
1. .Delivery and Installation Plan developed with City Project
Manager and Design Team
2. Successful installation of Artwork.
3. Final inspection of the Artwork immediately after
installation.
4. Final inspection by the City of Dublin and closed permits.
DUE DATE:
January 10, 2019 (EST)
July 10, 2019 (EST)
July 10, 2019 (EST)
Within 30 Days of Installation
5. Receipt of Artwork Maintenance Records Within 30 Days of Installation
EXHIBIT C
PAYMENT SCHEDULE
I TOTAL ARTIST FEE $500,000
10%
10%
$50,000
EXECUTION
Execution of Contract
.....................................................................
.................................................. ............................ ..... .
....... .........................
10%
...........................
20%
....................................... —.-
$50,000
Phase I
Engineering
- ...............................................................
--- I .......... --- 1-1- ........ .... . ................................................. ..........
... . ............... -- ............
20%
......................................
40%
................. . . —1-1--1.1
$100,000
Phase 11
Clay Models
.......... -.- .............................. .......................
.......... .............. ..........................................
............... 11 .................
20%
......................................
60%
................. ..............
$100,000
Phase Ill
Molds to the Foundry
..' ..................................................................
.............. "I - ........................................................................ -
. .... ............ ...........................
20%
........................ .
80%
...............................................
$100,000
Phase IV
Bronze Cast, Concrete/Electrical
11 ........................................................
i ................ . . ....... ...............................................
I
....................... - -.-- .....
20%
.......................................
100%
.............................. -- ------------
$100,000
Phase V
Installation and Closeout
I TOTAL ARTIST FEE $500,000