HomeMy WebLinkAboutReso 188-15 Wallis Ranch Tr 7713 Imp Agmt RESOLUTION NO. 188 - 15
A RESOLUTION OF THE CITY COUNCIL
OF THE CITY OF DUBLIN
APPROVING FINAL MAP AND TRACT IMPROVEMENT AGREEMENT
FOR TRACT 7713, WALLIS RANCH, NEIGHBORHOOD 3
WHEREAS, the Final Map for Tract 7713, in the incorporated territory of the City of
Dublin, State of California, has been presented to this City Council for approval, all in
accordance with provisions of the Subdivision Map Act of the State of California and the City of
Dublin Municipal Code; and
WHEREAS, the Developer, Taylor Morrison of California, LLC, has executed and filed
with the City of Dublin a Tract Improvement Agreement for Tract 7713 to construct required
subdivision improvements in accordance with the Conditions of Approval for Tentative Tract
Map 7713, and with the improvement plans attached thereto; and
WHEREAS, said Tract Improvement Agreement is secured by the following bond
furnished by National Union Fire Insurance Company of Pittsburgh, PA:
• $ 1,010,104.00 for the Tract 7713 Tract Improvements (Bond No. 919088)
conditioned upon faithful performance of said Agreement; and
WHEREAS, said Tract Improvement Agreement is secured by the following bond
furnished by National Union Fire Insurance Company of Pittsburgh, PA:
• $ 1,010,104.00 for the Tract 7713 Tract Improvements (Bond No. 919088)
conditioned upon payment for labor performed or material furnished under the terms of said
Agreement;
NOW, THEREFORE, BE IT RESOLVED that said Tract Improvement Agreement and
bonds are hereby approved.
BE IT FURTHER RESOLVED that the City Manager of the City of Dublin is hereby
authorized to execute said Tract Improvement Agreement, Tract 7713, attached hereto as
Exhibit A.
BE IT FURTHER RESOLVED that the Final Map of Tract 7713 be and the same is
hereby approved, and that rights to the areas marked as Public Service Easement (PSE) and
Emergency Vehicle Access Easement (EVAE), offered for dedication for public use in
conformity with the terms of dedication be, and they are hereby accepted, subject to
improvement, and that the Clerk of this City Council is hereby directed to transmit said Map to
the County Recorder for filing.
Page 1 of 2
PASSED, APPROVED AND ADOPTED this 15th day of December, 2015, by the
following vote:
AYES: Councilmembers Biddle, Gupta, Hart, Wehrenberg, and Mayor Haubert
NOES: None
ABSENT: None
ABSTAIN: None
A_ _ il4r
Mayor
ATTEST:
6C-)(
City Clerk
Reso No. 188-15,Adopted 12-15-15, Item 4.10 Page 2 of 2
CITY OF DUBLIN
TRACT IMPROVEMENT AGREEMENT
TRACT 7713
This agreement is made and entered into this 1st day of December, 2015, by and between the
City of Dublin, a municipal corporation, hereinafter referred to as"CITY", and Taylor Morrison of
California, LLC, hereinafter referred to as"DEVELOPER".
RECITALS
WHEREAS, it has been determined by the CITY Council of the CITY of Dublin, State of
California, that DEVELOPER, the subdivider of Tract No. 7713, desires to improve those
improvements (hereafter"The Improvements") required by City of Dublin City Council Resolution No.
68-14 adopted on May 20, 2014 for Tract 7713 in accordance with the requirements and conditions
set forth in said resolution, the requirements of the Subdivision Map Act of the State of California, the
Subdivision Ordinance of the CITY, and those certain plans for said development entitled
• Rough Grading Plans— Tract 7713—Neighborhood 3 at Wallis Ranch, prepared by MacKay&
Somps, and signed by the City Engineer •
• Improvement Plans— Tract 7713—Neighborhood 3 at Wallis Ranch, prepared by MacKay&
Somps, and signed by the City Engineer
• Joint Trench&Private Street Lighting Plans— Tract 7713—Neighborhood 3 at Wallis Ranch,
prepared by Giacalone Design, Inc., and signed by the City Engineer
• Landscape Plans—Tract 7713—Neighborhood 3 at Wallis Ranch, prepared by Gates&
Associates, and signed by the City Engineer
and now on file in the office of the City Engineer,which are hereby referred to for a more definite and
distinct description of the work to be performed under this Agreement as though set forth at length
herein;
WHEREAS, DEVELOPER intends to satisfactorily complete The Improvements within the time.
hereinafter specified, and CITY intends to accept DEVELOPER's offer(s) of dedication of The
Improvements in consideration for DEVELOPER's satisfactory performance of the terms and
conditions of this Agreement; and
WHEREAS, CITY has determined that the portion of The Improvements that will be accepted
by the City as Public improvements are a public works subject to California prevailing wage
requirements:
•
NOW, THEREFORE, in consideration of the mutual promises, conditions and covenants
herein contained, the parties agree as follows:
1. Completion Time.
DEVELOPER shall complete said work not later than two years following said date of
execution. Time is of the essence in this Agreement. Upon completion, DEVELOPER shall furnish
CITY with a complete and reproducible set of final Record Drawings of The Improvements, including
•
•
any modifications made during construction.
2. Estimated Cost of Improvements.
1
The estimated cost of constructing The Improvements required by this agreement are
presented in the Bond Estimate, Wallis Ranch—Neighborhood 3 Improvement& Grading Plans,
dated October 1, 2015, prepared by MacKay&Somps:
• Tract 7713 Improvements $1,010,104.00
Said amount includes costs and reasonable expenses and fees which may be incurred in enforcing
the obligation secured. Said amount reflects that the Tract 7713 Improvements are currently 0%
complete (bond is for 100% of the full amount). The bond estimate is attached as Exhibit A to this
agreement.
Bonds Furnished.
Concurrently with the execution of this Agreement, DEVELOPER shall furnish CITY with the
following security in a form satisfactory to the CITY Attorney:
Faithful Performance. Either a cash deposit, a corporate surety bond issued by a company
duly and legally licensed to conduct a general surety business in the State of California, or an
instrument of credit equivalent to one hundred per cent(100%) of the estimate set forth in Paragraph
2 and sufficient to assure CITY that The Improvements will be satisfactorily completed (collectively,
the"Faithful Performance Bond").
Labor and Materials. Either a cash deposit, a corporate surety bond issued by a company
duly and legally licensed to conduct a general surety business in the State of California, or an
instrument of credit equivalent to one-hundred per cent(100%)of the estimate set forth in Paragraph
2 and sufficient to assure CITY that DEVELOPER'S contractors, subcontractors, and other persons
furnishing labor, materials, or equipment shall be paid therefore (collectively, the"Labor and Materials
Bond").
CITY shall be the sole indemnitee named on any instrument required by this Agreement. Any
instrument or deposit required herein shall conform with the provisions of Chapter 5 of the Subdivision
Map Act.
3. Insurance Required.
Prior to commencing construction of the improvements, DEVELOPER shall obtain or cause to
be obtained and filed with the CITY, all insurance required under this paragraph Prior to the
commencement of work under this Agreement, DEVELOPER's general contractor(if different than
Developer)shall obtain or cause to be obtained and filed with the Administrative Services Director, all
insurance required under this paragraph. DEVELOPER shall not allow any contractor or subcontractor
to commence work on this contract or subcontract until all insurance required for DEVELOPER and
DEVELOPER's general contractor shall have been so obtained and approved. Said insurance shall
be maintained in full force and effect until the completion of work under this Agreement and the final
acceptance thereof by CITY. All requirements herein provided shall appear either in the body of the
insurance policies or as endorsements and shall specifically bind the insurance carrier.
A. Minimum Scope of Insurance. Coverage shall be at least as broad as:
1) Insurance Services Office form number GL 0002 (Ed. 1/73) covering
comprehensive General Liability and Insurance Services Office form number GL 0404
2
covering Broad Form Comprehensive General Liability; or Insurance Services Office
Commercial General Liability coverage ("occurrence"form CG 0001.)
2) Insurance Services Office form number CA 0001 (Ed. 1178)covering
Automobile Liability, code 1 "any auto"and endorsement CA 0025.
3) Workers' Compensation insurance as required by the Labor Code of the State
of California and Employers Liability Insurance.
B. Minimum Limits of Insurance. DEVELOPER shall maintain limits no less than:
1) General Liability: $1,000,000 combined single limit per occurrence for bodily
injury, personal injury and property damage. If commercial General Liability Insurance
or other form with a general aggregate limit is used, either the general aggregate limit
shall apply separately to this project/location or the general aggregate limit shall be
twice the required occurrence limit.
2) Automobile Liability: $1,000,000 combined single limit per accident for bodily
injury and property damage.
3) Workers'Compensation and Ejnployers Liability: Workers'compensation
limits as required by the Labor Code of the State of California and Employers Liability
limits of$1,000,000 per accident.
C. Deductibles and Self-Insurance Retentions.Any deductibles or self-insured
retentions must be declared to and approved by the CITY. DEVELOPER hereby declares that
the insurance required under Paragraph 3(B)(1)contains (i) a$1,000,000 per occurrence self-
insured retention for Bodily Injury and Property Damage Liability, (ii) a $2,000,000 per
occurrence self-insured retention for third party action over actions and (iii) a $7,500,000 per
occurrence self-insured retention for Home Builder's Limited Warranty Coverage, Construction
Damage Liability Coverage and Fungi and Related Medical Payments ("GL SIR's"). The CITY
hereby approves the GL SIR's.
D. Other Insurance Provisions. The policies are to contain, or be endorsed to •
contain, the following provisions:
1) General Liability and Automobile Liability Coverages.
a) The CITY, its officers, agents, officials, employees and volunteers shall
be named as additional insureds as respects: liability arising out of
activities performed by or on behalf of the DEVELOPER; products and
completed operations of the DEVELOPER; premises owned, occupied
or used by the DEVELOPER; or automobiles owned, leased, hired or
borrowed by the DEVELOPER. The coverage shall contain no special
limitations on the scope of the protection afforded to the CITY, its
officers, officials, employees or volunteers.
b) The DEVELOPER's insurance coverage shall be primary insurance as
respects the CITY, its officers, officials, employees and volunteers. Any
insurance or self-insurance maintained by the CITY, its officers, officials,
employees or volunteers shall be excess of the DEVELOPER'S
insurance and shall not contribute with it.
3
c) Any failure to comply with reporting provisions of the policies shall not
affect coverage provided to the CITY, its officers, officials, employees or
volunteers.
d) The DEVELOPER's insurance shall apply separately to each insured
against whom claim is made or suit is brought, except with respect to
the limits of the insurers liability.
2) Workers' Compensation and Employers Liability Coverage. The insurer shall
agree to waive all rights of subrogation against the CITY, its officers, officials,
employees and volunteers for losses arising from work performed by the DEVELOPER
for the CITY.
3) All Coverages. Each insurance policy required by this clause shall be
endorsed to state that coverage shall not be suspended, voided, cancelled by either
party, reduced in coverage or in limits except after thirty (30) days' prior written notice
by certified mail, retum receipt requested, has been given to the CITY.
Notwithstanding the foregoing, if an endorsement that would provide for thirty(30)
days' prior written notice prior to one or more of the above actions is not commercially
available, DEVELOPER shall be excused from providing an endorsement covering
said action or actions, provided that in such circumstances, DEVELOPER shall give
written notice to the CITY as soon as is practicable if DEVELOPER learns that its
coverage has been suspended, voided, cancelled by either party or reduced in
coverage or in limits.
a) Acceptability of Insurers. Insurance is to be placed with insurers with a
Bests'rating of no less than A:VII.
b) Verification of Coverage. DEVELOPER shall furnish CITY with
certificates of insurance and with original endorsements effecting
coverage required by this clause. The certificates and endorsements for
each insurance policy are to be signed by a person authorized by that
insurer to certify coverage on its behalf. The certificates and
endorsements are to be received and approved by the CITY before
work commences. The CITY reserves the right to require complete,
certified copies of all required insurance policies, at any time provided;
however, that if the policies are not yet available, the City will accept
copies of the applicable binders.
c) Subcontractors. DEVELOPER and/or DEVELOPER's general
contractor shall include all subcontractors as insureds under its policies
or shall obtain separate certificates and endorsements for each
subcontractor. All coverages for subcontractors shall be subject to all of
the requirements stated herein.
4. Work Performance and Guarantee.
Except as otherwise expressly provided in this Agreement, and excepting only items of routine
maintenance, ordinary wear and tear and unusual abuse or neglect, DEVELOPER guarantees all
work executed by DEVELOPER and/or DEVELOPER's agents, and all supplies, materials and
4
devices of whatsoever nature incorporated in, or attached to the work, or otherwise delivered to CITY
as a part of the work pursuant to the Agreement,to be free of all defects of workmanship and
materials for a period of one (1) year after initial acceptance of the entire work by CITY.
DEVELOPER shall repair or replace any or all such work or material, together with all or any other
work or materials which may be displaced or damaged in so doing, that may prove defective in
workmanship or material within said one-year guarantee period without expense or charge of any
nature whatsoever to CITY. DEVELOPER further covenants and agrees that when defects in
workmanship and materials actually appear during the one-year guarantee period, and have been
corrected, the guarantee period for the defected items shall automatically be extended for an
additional year from the date of the completion of the repair to insure that such defects have actually
been corrected.
In the event the DEVELOPER shall fail to comply with the conditions of the foregoing
guarantee within thirty(30)days time, after being notified of the defect in writing, CITY shall have the
right, but shall not be obligated, to repair or obtain the repair of the defect, and DEVELOPER shall pay
to CITY on demand all costs and expense of such repair. Notwithstanding anything herein to the
contrary, in the event that any defect in workmanship or material covered by the foregoing guarantee
results in a condition which constitutes an immediate hazard to the public health, safety, or welfare,
CITY shall have the right to immediately repair, or cause to be repaired, such defect, and
DEVELOPER shall pay to CITY on demand all costs and expense of such repair. The foregoing
statement relating to hazards to health and safety shall be deemed to include either temporary or
permanent repairs which may be required as determined in the sole discretion and judgment of CITY.
If CITY, at its sole option, makes or causes to be made the necessary repairs or replacements
or performs the necessary work, DEVELOPER shall pay, in addition to actual costs and expenses of
such repair or work, fifty percent(50%) of such costs and expenses for overhead and interest at the
maximum rate of interest permitted by law accruing thirty (30) days from the date of billing for such
work or repairs.
5. Inspection of the Work.
DEVELOPER shall guarantee free access to CITY through its City Engineer and designated
representative for the safe and convenient inspection of the work throughout its construction. Said
CITY representative shall have the authority to reject all materials and workmanship which are not in
accordance with the plans and specifications, and all such materials and or work shall be removed
promptly by DEVELOPER and replaced to the satisfaction of CITY without any expense to CITY in
strict accordance with the improvement plans and specifications.
6. Agreement Assignment.
This Agreement shall not be assigned by DEVELOPER without the written consent of CITY.
7. Abandonment of Work.
Neither DEVELOPER nor any of DEVELOPER's agents or contractors are or shall be
considered to be agents of CITY in connection with the performance of DEVELOPER's obligations
under this Agreement.
If DEVELOPER refuses or fails to obtain prosecution of the work, or any severable part
thereof, with such diligence as will insure its completion within the time specified, or any extension
thereof, or fails to obtain completion of said work within such time, or if DEVELOPER should be
adjudged as bankrupt, or should make a general assignment for the benefit of DEVELOPER's
5
•
creditors, or if a receiver should be appointed, or if DEVELOPER, or any of DEVELOPER's
contractors, subcontractors, agents or employees should violate any of the provisions of this
Agreement,the CITY through its City Engineer may serve written notice on DEVELOPER and
DEVELOPER's surety or holder of other security of breach of this Agreement, or of any portion,
thereof, and default of DEVELOPER, and DEVELOPER shall have fifteen (15)days after receipt of
such written notice to cure such default; provided that, if such cure cannot be reasonably effected
within such fifteen (15)day period, such failure shall not be a default hereunder so long as
DEVELOPER commences to cure such default in such fifteen (15)day period, and thereafter
diligently prosecutes such cure to completion.
In the event of any such notice of breach of this Agreement, DEVELOPER's surety shall have
the duty to take over and complete The Improvements herein specified; provided, however, that if the
surety, within thirty(30)days after the serving upon it of such notice of breach, does not give CITY
written notice of its intention to take over the performance of the contract, and does not commence
performance thereof within thirty(30)days after notice to CITY of such election, CITY may take over
the work and prosecute the same to completion, by contract or by any other method CITY may deem
advisable, for the account and at the expense of DEVELOPER and DEVELOPER's surety shall be
liable to CITY for any damages and/or reasonable and documented excess costs occasioned by CITY
thereby; and, in such event, CITY, without liability for so doing, may take possession of, and utilize in
completing the work, such materials, appliances, plant and other property belonging to DEVELOPER
as may be on the site of the work and necessary therefore.
AN notices herein required shall be in writing, and delivered in person or sent by registered
mail, postage prepaid.
Notices required to be given to CITY shall be addressed as follows:
City Engineer
City of Dublin
100 Civic Plaza
Dublin, CA 94568
Notices required to be given to DEVELOPER shall be addressed as follows:
Taylor Morrison of California, LLC
81 Blue Ravine Road
Suite 220
Folsom, CA 95630
Attn. Jennifer Besmer
Phone: (925) 983-4690
Email: JBesmer@taylormorrison.com
Notices required to be given surety of DEVELOPER shall be addressed as follows:
Any party or the surety may change such address by notice in writing to the other party and
thereafter notices shall be addressed and transmitted to the new address.
6
8. Use of Streets or Improvements.
At all times prior to the final acceptance of the work by CITY, the use of any or all streets and
improvements within the work to be performed under this Agreement shall be at the sole and
exclusive risk of DEVELOPER. The issuance of any building or occupancy permit by CITY for
dwellings located within the tract shall not be construed in any manner to constitute a partial or final
acceptance or approval of any or all such improvements by CITY. DEVELOPER agrees that CITY's
Building Official may withhold the issuance of building or occupancy permits when the work or its
progress may substantially and/or detrimentally affect public health and safety.
9. Safety Devices.
DEVELOPER shall provide and maintain such guards, watchmen, fences, barriers, regulatory
signs, warning lights, and other safety devices adjacent to and on the tract site as may be necessary
to prevent accidents to the public and damage to the property. DEVELOPER shall furnish, place, and
maintain such lights as may be necessary for illuminating the said fences, barriers, signs, and other
safety devices. At the end of all work to be performed under this Agreement, all fences, barriers,
regulatory signs,warning lights, and other safety devices (except such safety items as may be shown
on the plans and included in the items of work) shall be removed from site of the work by the
DEVELOPER, and the entire site left clean and orderly.
10. Acceptance of Work.
Upon notice of the completion of The Improvements and the delivery of a set of final as-built
plans to CITY by DEVELOPER, CITY, through its City Engineer or his designated representative,
shall examine The Improvements without delay, and, if found to be in accordance with said plans and
specifications and this Agreement, and upon submittal of a warranty bond in the amount of 25% of the
estimated cost of The Improvements that are within the Public right-of-way or Public easements, shall
recommend acceptance of the work to the City Council and, upon such acceptance, shall notify
DEVELOPER or his designated agents of such acceptance and shall thereafter immediately release
the Faithful Performance Bond and the Labor and Materials Bond. The City will not accept the Private
Improvements and a warranty bond will not be needed for these Improvements; provided however,
the CITY shall examine the Private Improvements as set forth above and shall notify DEVELOPER or
his designated agents of their completion and shall thereafter immediately release the Faithful
Performance Bond and the Labor and Materials Bond.
11. Patent and Copyright Costs.
In the event that said plans and specifications require the use of any material, process or
publication which is subject to a duly registered patent or copyright, DEVELOPER shall be liable for,
and shall indemnify CITY from any fees, costs or litigation expenses, including attorneys'fees and
court costs, which may result from the use of said patented or copyrighted material, process or
publication.
12. Alterations in Plans and Specifications.
Any alteration or alterations made in the plans and specifications which are a part of this
Agreement or any provision of this Agreement shall not operate to release any surety or sureties from
liability on any bond or bonds attached hereto and made a part hereof, and consent to make such
alterations is hereby given, and the sureties to said bonds hereby waive the provisions of Section
2819 of the Civil Code of the State of California.
7
13. Liability.
•
A. DEVELOPER Primarily Liable. DEVELOPER hereby warrants that the design and
construction of The Improvements will not adversely affect any portion of adjacent properties
and that all work will be performed in a proper manner. DEVELOPER agrees to indemnify,
defend, release, and save harmless CITY, and each of its elective and appointive boards,
commissions, officers agents and employees, from and against any and all loss, claims, suits,
liabilities, actions, damages, or causes of action of every kind, nature and description, directly
or indirectly arising from an act or omission of DEVELOPER, its employees, agents, or
independent contractors in connection with DEVELOPER'S actions and obligations hereunder;
provided as follows:
1) That CITY does not, and shall not, waive any rights against DEVELOPER
which it may have by reason of the aforesaid hold harmless agreement, because of the
acceptance by CITY, or the deposit with CITY by DEVELOPER, of any of the
insurance policies described in Paragraph 4 hereof.
2) That the aforesaid hold harmless agreement by DEVELOPER shall apply to
all damages and claims for damages of every kind suffered, or alleged to have been
suffered, by reason of any of the aforesaid operations referred to in this paragraph,
regardless of whether or not CITY has prepared, supplied, or approved of plans and/or
specifications for the subdivision, or regardless of whether or not such insurance
policies shall have been determined to be applicable to any of such damages or claims
for damages.
3) Design Defect. If, in the opinion of the CITY, a design defect in the work of
improvement becomes apparent during the course of construction, or within one(1)
year following acceptance by the CITY of the improvements, and said design defect, in
the opinion of the CITY, may substantially impair the public health and safety,
DEVELOPER shall, upon order by the CITY, correct said design defect at his sole cost
and expense, and the sureties under the Faithful Performance and Labor and Materials
Bonds shall be liable to the CITY for the corrective work required.
4) Litigation Expenses. In the event that legal action is instituted by either
party to this Agreement, and said action seeks damages for breach of this Agreement
or seeks to specifically enforce the terms of this Agreement, and, in the event judgment
is entered in said action, the prevailing party shall be entitled to recover its attorneys'
fees and court costs. If CITY is the prevailing party, CITY shall also be entitled to
recover its attorney's fees and costs in any action against DEVELOPER's surety on the
bonds provided under paragraph 3.
14. Recitals.
The foregoing Recitals are true and correct and are made a part hereof.
•
8
•
IN WITNESS WHEREOF,the parties hereto have executed this Agreement in duplicate at
Dublin, California, the day and year first above written.
CITY OF DUBLIN
By:
City Manager
ATTEST:
City Clerk
DEVELOPER
Tay lof Morrison of California, LLC
•
•
••.
By: ••-•
`.. •
Authorized Representative
•
• GMEVELOPNENT,PRIVATEIWaNs Ranch-N3-Tr 7713AgreamanlalnA-Taylor Morrison-Tr 7713,dx
9
•
CALIFORNIA ALL- PURPOSE
CERTIFICATE OF ACKNOWLEDGMENT
A notary public or other officer completing this certificate verifies only the identity J
of the individual who signed the document to Which this certificate is attached,
i i and not the truthfulness, accuracy, or validity of that document.
State of California }
•
County of ' I _..l a
�
On; . i, cf'l i + 'before men. . i L, ,..fit .,y,.�t. L--1, ?x'40.1 y,,< "/) jr , • 1
! ...; , .., iFtas Iran name mature ame r !>�f> I:.`• _
personally appeared -_.. #�`,.•1^i..4 , 2.r ? e � 'v4-j , .
who proved to me on the basis of satisfactory evidence to be the person(e)whose
name(s)®are subscribed to the within instrument and acknowledged to me that
1 he/ they executed the same in hi-( r their authorized ca act by
hi-(Cr eir signature(e) on the instrument the erson p � �
t }' and that person(e) p (s), or the entity upon behalf f
of
l'. which the p (s) acted, executed the instrument.
I. I certify under PENALTY OF PERJURY under the laws of the State of California that
•
the foregoing paragraph is true and correct. 1
TERRI LYNNE CLARK .
WITNESS my hand and official seal. L�'- ' �'' Commission I►io.
r�,� r 2 .�` '.' NGTAcw anent-CALIF IA 2 i
''- s w''.r'-'�"�' kjf ' 't. �y- My Cot Expires NODE 8,201i I' •
i N- L/••
otary Publ Si�tittllre (Notary Pubic Seal) .•
- ...- - .. .
'' ADDITIONAL OPTIONAL INFORMATION ; INSTRUCTIONS FOR COMPLETING TIi[S•FORIbI
T
•
his fom complies with current Cal(fornla matinee regarding notary wonting mid. 1
1 DESCRIPTION OF THE ATTACHED DOCUMENT (f needed should be eonpleted and attached to the document.Aeirtowledgeien� , ■
from other states may be completed for document!being arm in that sate so long '
lawhe wording does not require the Cedronefo notary to violate California notary .
i (Title or description of attached document) • State and County information must be the State and County where the document
_ signer(s)personally appealed before the notary public for acknowledgment •
f {Title or description of attached document eentinuedj - • Date of notarization must be the date that the signcr(s)poly appeared which
trust also be the same date the acknowedgment it compkxed.
Number of Pages Document Date • The notary public most print his or her name as it appears within his or her
commis followed by a comma and then your tide(notary public). .7 1'
•
• Print the name(s) of document signets)who personally appear at the time of I
CAPACITY CLAIMED BY THE SIGNER • hulicate the correct singular or :;
plural roans by craasirg off incorrect Gums(i.e.
121 Individual(s) he/she/66y;is%era)or circling the correct forms.Failure to correctly indicate this
information may lead to rejection of document recording.
i ❑ Corporate Officer • The notary seal
' tart' rmprmsion must he clear and photographically retroducibk.
I. (Title) Impression must not cover text or lines If seal impxcanion smudges,reseal if a ':
sufficient area permits,otherwise complete a difforent acknowledgmea form.
0 Partners) • Simature of the notary public must match the signature on tilt with the office of
I ❑ Attorney-in-Fad
eannty.clerk• f
4
•
Additional information is not required but could help m ensure this
❑ Trustee(s) acknowledgment is not misused or attached to a dill'axent doctunuml,
r
Other 4. huficate title or type of attached document,number of pages and dam.
I - 4 I
r
•
Inditmte the capacity claimed by the signer. If the claimed capacity is a
the ( . Secretary).
'2015 Version www.NotaryClasses.cant 800•873-8865 • Securely attach this document to the ge document w ith a staple.
- 7
19604-030
Revised 10/112015
BOND ESTIMATE
WALLIS RANCH-NEIGHBORHOOD 3 IMPROVEMENT&GRADING PLANS DATED SEPTEMBER 2015
City of Dublin
ITEM QUANTITY UNIT DESCRIPTION UNIT PRICE AMOUNT
A. STREETWORK
1. 60,625 SF Finish grading street 0.40 $24,250
2. 60,625 SF Pavement Section (3"AC!12"AB) 3.50 212,190
3. 10,715 SF 4"AB under Driveway 0.72 7,710
4. 5,600 SF 4"AB under rolled curb&gutter 0.72 4,030 •
5. 608 SF 4"AB under standard 6"curb&gutter 0.72 440
6. 940 SF 4"AB under 6"concrete band 0.72 680
7. LUMP SUM Signing&Striping 5,000
8. 2,240 LF 4"PVC Gutter sub drain (under rolled curb only) 9.50 21,280
9. 6 EA Pavement Reflectors at Fire hydrants 3.00 20
10. 3,700 SF Paved multi-use trait(3"AC on 9"AB) 3.00 11,100
11. 8 EA Street Name Sign 250.00 2,000 •
12. 4 EA Stop sign, stop bar and legend 500.00 2,000
13. 4 LA Traffic signs 250.00 1,000
ESTIMATED TOTAL STREET WORK: $291,700
B. CONCRETE WORK
1. 2,175 LF Rolled curb&Gutter 15.00 $32,630
2. 355 LF Standard 6"curb&gutter 15.00 $5,330
3. 2,000 LF 6"wide concrete band 10.00 $20,000
4. 18 EA Curb Inlet 4,200.00 75,600
5. 7 EA Field Inlet 2,000.00 14,000
6. 4,136 SF 4"Concrete walkway 4.00 16,540
7. 4,138 SF 4"AB under concrete walkway 0.72 2,980 •
•
ESTIMATED TOTAL CONCRETE WORK: $167,080
C. STORM DRAIN WORK
1. 1,785 LF 18" HDPE Storm drain pipe 45.00 80,330
2. 850 LF 6"HDPE Storm drain pipe 10.00 8,500
3. 517 LF 8"HDPE Storm drain pipe 30.00 15,510
4. 3 EA Connect to Existing 2,000.00 6,000
5. 74 EA 4"SD stub(Lot Drainage) 500.00 37,000
ESTIMATED TOTAL STORM DRAIN WORK: $147,340 .
•
19131-Nithbahnod 3 B d estZu b[n-20160023.ba Page 1 of 3
19604-030
Revised 10/1/2015
D. ELECTRICAL/JOINT TRENCH
1. 16 EA Single arm"Decorative"electrolier including 3,500.00 $56,000
conduit&boxes
2. 2,220 LF Joint Trench(length of improvements) 60.00 133,200
ESTIMATED TOTAL ELECTRICAL WORK: $189,200 II
E.ROUGH GRADING
1. 17 EA Survey Monuments 300.00 $5,100
ESTIMATED TOTAL ROUGH GRADING WORK: $5,100
F. EROSION CONTROL
1. LUMP SUM Erosion Control $50,000
ESTIMATED TOTAL EROSION CONTROL: $50,000
G. MISCELLANEOUS CONSTRUCTION
1. 200 LF 6"irrigation sleeves 12.00 $2,400
2. 2 EA Removable bollard 260,00 $500
3. 27 EA Wheel Stop 100.00 $2,700
ESTIMATED TOTAL MISC.CONSTRUCTION: $5,600
SUMMARY
A STREETWORK $291,700
B CONCRETE WORK 167,080
C STORM DRAIN WORK 147,340
D ELECTRICAL/JOINT TRENCH 189,200 -
E ROUGH GRADING 5,100
F EROSION CONTROL 50,000
G MISCELLANEOUS CONSTRUCTION 5,600
ESTIMATED IMPROVEMENT COST: $856,020
CONTINGENCY(10%) $85,602
ENGINEERING FEES(8%) $68,482
TOTAL BOND ESTIMATE: $1,010,104
+Y1tl4 a0ghbarhooas Band.K.Ouat40131323 Page 2 of 3
19604-030
Revised 10/1/2015
NOTE
1. This estimate is prepared as a guide only and is subject to possible change. It has been
prepared to a standard of accuracy which,to the best of our knowledge and judgment, is
sufficient to satisfy our understanding of the purposes of this estimate. MacKay&Somps
makes no warranty, either expressed or implied, as to the accuracy of this estimate.
Prepared by the firm of
MACKAY&SOMPS
fi
}F1
111104PMlpdbghaod 3 Bond antQIbNn-20130627A,
Page 3 of 3