HomeMy WebLinkAboutReso 182-15 Jordan Rch Improv Agmt RESOLUTION NO. 182 - 15
A RESOLUTION OF THE CITY COUNCIL
OF THE CITY OF DUBLIN
* * * * * * * * * * *
APPROVING THE IMPROVEMENT AGREEMENT WITH BJP-ROF JORDAN RANCH, LLC FOR
JORDAN RANCH NEIGHBORHOOD PARK
WHEREAS, BJP-ROF Jordan Ranch, LLC ("Developer") owns portions of certain real property
consisting of approximately 187.9-acres of land generally northeast of the intersection of Fallon Road
and Central Parkway on which it is pursuing a residential development project; and
WHEREAS, the Developer will dedicate a 4.99-acre Neighborhood Park within Tract 8024 to
satisfy Neighborhood Park Land dedication obligations, for which has received Neighborhood
Parkland fee credits under the City's Public Facilities Fee Program; and
WHEREAS, the Developer and the City have proposed to enter into an Improvement
Agreement for Jordan Ranch to develop the 4.99-acre Neighborhood Park with the Developer
receiving partial Neighborhood Park Improvement fee credits under the City's Public Facilities Fee
Program as agreed in the Development Agreement Amendment with BJP-ROF Jordan Ranch, LLC
approved by Ordinance 10-15; and
WHEREAS, said Improvement Agreement will be secured by a bond furnished after execution
of the agreement and prior to issuing the credits for the improvements, conditioned upon faithful
performance of said Agreement; and
WHEREAS, said Improvement Agreement is secured by a bond furnished after execution of
the agreement and prior to issuing the credits for the improvements, conditioned upon payment for
labor performed or materials furnished under the terms of the said Agreement.
NOW, THEREFORE, BE IT RESOLVED that the City Council of the City of Dublin does
hereby approve an Improvement for Jordan Ranch Neighborhood Park with BJP-ROF Jordan Ranch,
LLC attached hereto as Exhibit A.
PASSED, APPROVED AND ADOPTED this 17th day of November, 2015, by the following
vote:
AYES: Councilmembers Biddle, Gupta, Hart, Wehrenberg, and Mayor Haubert
NOES: None
ABSENT: None
ABSTAIN: None
e f �r
ayor
ATTEST:
at4 4(6-
City Clerk
Reso No.182-15,Adopted 11-17-15, Item 4.16 Page 1 of 1
IMPROVEMENT AGREEMENT FOR
JORDAN RANCH PARCEL D (NEIGHBORHOOD PARK SITE)
THIS IMPROVEMENT AGREEMENT (this "Agreement") is made and entered in
the City of Dublin on this 17th day of November, 2015 by and between the City of Dublin,
a Municipal Corporation (hereafter"City") and BJP-ROF Jordan Ranch, LLC, a California
Corporation (hereafter "Landowner"). City and Landowner are hereinafter collectively
referred to as the"Parties."
WITNESSETH:
WHEREAS, Landowner owned, and still owns portions, of certain real property
("the Property") consisting of approximately 187.9-acres of land generally northeast of
the intersection Fallon Road and Central Parkway, on which it is pursuing a development
project("the Project"); and
WHEREAS, in pursuit of the Project, Landowner and' City entered into a
Development Agreement with the City, dated June 22, 2010, recorded on July 27, 2010
as Instrument No. 2010206466 of the Official Records of Alameda County
("Development Agreement"); and
WHEREAS, Landowner filed" Tract Map 8024 in 2011, which reserved a 4.99
acre park site, and indicated that it would be conveyed to the City of Dublin by
subsequent instrument; and
WHEREAS, Landowner recently sought, and the City approved, certain changes
to the project entitlements, including an ameidment to the Development Agreement,
which among other things, obligates Landowner to improve the 4.99-acre Neighborhood
Park at the Developer's cost, with a portion of the costs of the improvements being a
9 y'S Neighborhood Improvement component of the Public
credit against the Cit Nei hborhpod Park �Im
Facilities Fee Program; and
I'WHEREAS, Landowner ,agrees to satisfactorily complete the improvements
time hereaftet specified, and the City intends to accept Landowner's offer of
within the .o
dedicatiof the land an improvarjents in consideration for Landowner's satisfactory
,�
performance of the terms and conditions of this Agreement; and
WHEREAS, except as 1I otherwise defined herein, all capitalized terms used but
not defined in this Agreement shall correspond to the defined terms in the Development
Agreement.
NOW, THEREFORE, City and Landowner agree as follows:
1. Land Dedication. The Landowner, concurrently with the execution of
this Agreement, has delivered an offer of dedication to the City the acceptance of which
would convey to the City the approximately 4.99-acre neighborhood park parcel
(designated Parcel "D" on the final map for Tract 8024) (the "Neighborhood Park"). The
City will accept the dedication upon its acceptance of the Improvements pursuant to
Section 4.
1
2. Construction Documents. The City has prepared construction plans and
specifications for the Improvements, dated August 27, 2015, and on file with the Parks
and Community Services Director.
3. Completion Time. Landowner will commence construction of the
Improvements by March 1, 2016, provided that the City has provided the plans by
January 15, 2016, and shall complete all Improvements no later than March 1, 2017
except as extended by weather delays as allowed for in the City's standard
specifications or unless the completion date is extended by the City Council. Developer
shall maintain the improvements for three months following substantial completion. Time
is of the essence in this Agreement. Upon completion, Landowner shall furnish City with
a complete and reproducible set of final as-built plans and AutoCAD copies of the
Construction Documents for the Improvements, Including any City authorized
modifications.
4. Acceptance of Work. Upon notice of completion of all Improvements and
delivery of a set of final as-built plans copies of Construction Documents to City by
Landowner, the City shall examine the Improvements without., delay. If the
Improvements are found to be in accordance with said plans and specifications and this
Agreement, City shall recommend acceptance of the work to the City Council, and, upon
Y p
such acceptance, shall notify Landowner or its desi agents of such acceptance.
City shall only accept the Improvements at 100%completion.
5. Bid Documents. L shall sh II prepere the bid documents for the
Neighborhood Park. The City shall review and approve the bid documents prior to the
issuance of a notice of, and invitation to, bid by Landowner. Bids shall be lump sum with
an itemized unit summary to be used for additions and deletions only. The City shall be
permitted to review the bids received by Landowner and provide comments on them
prior to Landowner's selection of the most appropriate bid. All bids shall include
prevailing wage rates. The City Shall have ten.(10) working days to review the bids and,
in the event,the City concludes the bids are onacceptably high and not to budget, to
notify 'Landowner Of ,required modifications to the Improvements or the need to solicit
additional bids. The City shall provide Landowner with an opportunity to review and
comment on any proposal by the City to modify the Improvements and shall give such
comments fair consideration.
6. Inspection of the Work. Landowner shall guarantee free access to City
through the City Manager's designated representative for the safe and convenient
inspection of the work throughout its construction. Said City representative shall have
the authority to reject all materials and workmanship which are not in accordance with
the plans and specifications, and all such materials and or work shall be removed
promptly by Landowner and replaced to the satisfaction of City without any expense to
City in strict accordance with the improvement plans and specifications. The City
representative will also attend all project progress meetings during the course of
construction. Landowner shall submit any plan changes before and during construction
to the City Manager's designated representative for approval. Construction shall not
begin on any plan changes unless they are approved pursuant to Section 7 of this
Agreement.
7. Change Orders. Landowner shall submit a written request for approval of
any change orders to the City at least 15 working days prior to proceeding with any
2
change order. Landowner shall not issue any change orders on such construction
contract without first obtaining City's written consent. Landowner acknowledges the
failure to obtain such written consent from the City will result in Landowner's sole
responsibility to pay for such change orders without reimbursement or credit from the
City. Any change in design in the Improvements must have City's pre-approval.
8. Other Costs. City and Landowner acknowledge that City and Landowner
incur various costs during park development beyond construction document preparation
and improvement construction. Such costs include but are not limited to consultant
construction assistance (environmental, inspection, engineering), storm water pollution
prevention, utility bills (electric, water), City inspections, permits and fees, design/drafting
fees, fencing, maintenance and miscellaneous costs such as photocopying and printing.
Landowner shall not enter into contracts for such posts or otherwise procure such
services without obtaining City consent. Landowner will provide City with copies of any
contracts and detailed descriptions of scope of work to :tie performed. Landowner
acknowledges failure to obtain such written consent from the City will result in
Landowner's sole responsibility to pay for si.rch other costs without reimbursement or
credit from the City.
9. Payments. Landowner shall be responeipie for all payments associated
with the Improvements. This includes but is not limited to,contractors work, electric and
water bills, storm water pollution prevention, consultant construction assistance, City
inspections, permits and fees. Landowner shall provide to City a monthly accounting
summary outlining project costs to date.Landowner will include copies of invoices paid.
Landowner will provide copies of cancelled checks if requested,by City.
10. Work Performance and Guarantee. 'Except as otherwise expressly
provided in this Agreement, and excepting only items of routine maintenance, ordinary
wear and tear and unusual abuse or neglect, Landowner guarantees all work executed
an
by Landowner and/or� downer's,;agents, and all supplies, materials and devices of
)..
wh tsoeuernature incorporated in;Apr':attached, to the work, or otherwise delivered to
City as a part'Of the work pursuant to the Agreement, to be free of all defects of
worhrhanship and materials for a period of one year after final acceptance of the entire
work 1py_City. All manufactured I products specified for the site shall have extended
warranties as available frdni the companies that supply the products. All such warranties
shall be transferred to the City prior to final acceptance of the Improvements. These
warranties shall cover both the replacement of parts and the labor necessary to have the
equipment in proper working order. These products include, but are not limited to: play
equipment, site furnishings and mechanical equipment. Landowner shall repair or
replace any or all such work or material, together with all or any other work or materials
which may be displaced or damaged in so doing, that may prove defective in
workmanship or material within said one-year guarantee period without expense or
charge of any nature whatsoever to City. Landowner further covenants and agrees that
when defects in design, workmanship and materials actually appear during the
applicable guarantee period, and have been corrected, the guarantee period for such
corrected items shall automatically be extended for an additional year to insure that such
defects have actually been corrected. In the event the Landowner shall fail to comply
with the conditions of the foregoing guarantee within ten (10) days' time, after being
notified of the defect in writing, City shall have the right, but shall not be obligated, to
repair or obtain the repair of the defect, and Landowner shall pay to City on demand all
costs and expense of such repair. Notwithstanding anything herein to the contrary, in
3
the event that any defect in workmanship or material covered by the foregoing guarantee
results in a condition which constitutes an immediate hazard to the public health, safety,
or welfare, City shall have the right to immediately repair, or cause to be repaired, such
defect, and Landowner shall pay to City on demand all costs and expense of such
repair. The foregoing statement relating to hazards to health and safety shall be deemed
to include either temporary or permanent repairs, which may be required as determined
in the sole discretion and judgment of City. If City, at its sole option, makes or causes to
be made the necessary repairs or replacements or performs the necessary work as
provided herein, Landowner shall pay, in addition to actual costs and expenses of such
repair or work, fifty percent (50%) of such costs and expenses for overhead and interest
at the maximum rate of interest permitted by law accruing thirty (30) days from the date
of billing for such work or repairs.
11. Estimated Cost of Improvements. The estimated cost of constructing the
Improvements required by this Agreement as adjusted for inflation is agreed to be for a
fixed limit in the amount of $1,965,000 as more fully set out in Exhibit "B" entitled
"Complete Project Cost Estimate — Jordan 'Fanch Neighborhood Park Improvements"
and incorporated herein.
12. Bonds Furnished. Concurrently with the 'execution of this Agreement,
Landowner shall furnish City with the following sedUrity'in a form satisfactory to the City
Attorney. Landowner shall increase or decrease the amount of the security if project
costs increase or decrease pursuant to section 11.
m f duly and i h a cash deposit, a corporate surety
a. Faithful Performance. ether
bond issued by a cd 'pay du y a d eased to conduct a general surety
a California, or an instrument of credit equivalent to one hundred
business in the St te'of Califor
percent (100%) of the estimate set forth in Section 11 and sufficient to assure City that
the Park Improvements_will be satisfactorily completed.
II b. LabOt and Materials. Either a cash deposit, a corporate surety
bond 'issued by a pompar$r, duly and legally licensed to conduct a general surety
business in the State of California, or an instrument of credit equivalent to one-hundred
percent ( ) forth in Section 11 and sufficient to assure City that
ercbnt� 100% of the estimate set,
Landowner's contractors, subcontractors, and other persons furnishing labor, materials,
or equipment shall be paid therefore.
c. City shall be the sole indemnitee named on any instrument
required by this Agreement. Any instrument or deposit required herein and the release
thereof shall conform with the provisions of Chapter 5 of the Subdivision Map Act.
13. Fee Credit For Park Improvement. In consideration for the Improvements
to be constructed by Landowner, City shall, upon Landowner's posting the security
required by Section 12, grant Landowner Public Facilities Fee credits in the form of an
exemption from the neighborhood park improvement component for the 45 residential
units proposed on Parcel H of Tract 8024 and for the 105 residential units proposed on
Parcel A of Tract 8100 (former School Site). The parties agree that the monetary value
of those credits is presently approximately $365,000, which amount will change from
time to time as a result of periodic changes in the amount of the Public Facilities Fee.
Landowner will not receive credits for the additional costs of the improvements that
exceed the value of the exemption provided by this paragraph.
4
14. No Credit for Excess Costs. Costs are not subject to reimbursement by
City to Landowner to the extent that actual construction, design, and related costs, as
approved by City, total more than the above fee credit.
15. Obligations Arising from Agreement. Neither the General Fund nor any
other fund or monies of City shall be utilized for payment of any obligations arising from
this Agreement. Neither the credit nor the taxing power of City is pledged for the
payment of any obligations arising from the Agreement. Landowner's obligations arising
from this Agreement are not a debt of City, or a legal or equitable pledge, charge, lien or
encumbrance upon any of its property, or upon any of its income, receipts or revenues.
16. Liability.
a. Landowner Pn'
Primarily Liable. Landowner hereby warrants that th
e
design and construction of the Improvements will not adversely affect any portion of
adjacent properties and that all work will be performed in a proper irnanner. Landowner
agrees to indemnify, defend with counsel acceptable to City, and hbid harmless CITY, its
officers, officials, employees, agents, and vOlunteers, from and against,any and all loss,
claims, suits, liabilities, actions, damages, or 'causes of'action of every kind, nature and
description,(collectively "Liability") directly or indirectly arising from an act'drl omission of
Landowner, its employees, agents, or independent, contractors in connection with
Landowner's actions and obligations hereunder, except such Liabilities caused by the
sole negligence or willful misconduct;of the City; provided as follows:
1), That City does notand'shall not, waive any rights against
Landowner which it may have by reason, of the aforesaid hold harmless agreement,
because of the acceptance by city, or the deposit with City by Developer, of any of the
insurance policies described in Paragraph 19 hereof.
2) That the aforesaid hold harmless agreement by
Landbwrher shall apply to all damages and claims for damages of every kind suffered, or
alleged to have been suffered, by reason of any of the aforesaid operations referred to in
this paragraph, regardless of whether or not City has prepared, supplied, or approved of
plans and/or specifications for the subdivision, or regardless of whether or not such
insurance policies shall have been determined to be applicable to any of such damages
or claims for damages.
b. Design Defect. If, in the opinion of the City, a design defect in the
work of improvement,becomes apparent during the course of construction, or within one
(1) year (except for those manufactured products where extended warranties have been
provided, in which case the extended warranty period shall apply) following acceptance
by the City of the Improvements, and said design defect, in the opinion of the City, may
substantially impair the public health and safety, Developer shall, upon order by the
CITY, correct said design defect at his sole cost and expense, and the sureties under
the Faithful Performance and Labor and Materials Bonds shall be liable to the City for
the corrective work required.
c. Litigation Expenses. In the event that legal action is instituted by
either party to this Agreement, and said action seeks damages for breach of this
Agreement or seeks to specifically enforce the terms of this Agreement, and, in the
5
event judgment is entered in said action, the prevailing party shall be entitled to recover
its attorneys' fees and court costs. If City is the prevailing party, City shall also be
entitled to recover its attorney's fees and costs in any action against Landowner's surety
on the bonds provided under paragraph 12.
d. Third Party Claims. With respect to third party claims against the
Developer, the Developer waives any and all rights of any type to express or implied
indemnity against the City.
17. Insurance Required. Concurrently with the execution hereof, Landowner
shall obtain or cause to be obtained and filed with the City, all insurance required under
this paragraph, and such insurance shall have been approved by the Risk Manager of
City, or his designee, as to form, amount and carrier., Prior to the commencement of
work under this Agreement, Landowner's general contractor shall obtain or cause to be
obtained and filed with the Risk Manager, all insurance required under this paragraph,
and such insurance shall have been approved by the Risk Manager of City, as to form,
amount and carrier. Landowner shall not allow any contractor or subcontractor to
commence work on this contract or subcontract until all insUrance required for
Landowner and Landowner's general contractor shall have been $p obtained and
approved. Said insurance shall be maintained'in full force and effect until the completion
of work under this Agreement and,the final acceptance thereof by City. All requirements
herein provided shall appear either in the body' of the insurance policies or as
endorsements and shall specifically bind the insurance'carrier.
A. Minimum Scope of Insurance. Coverage shall be at least as
broad as:
1) Insurance Services Office form number GL 0002 (Ed. 1/73)
covering comprehenSiye General Liability and Insurance Services Office form number
GL 0404 covering Broad Form Comprehensive General Liability; or Insurance Services
Office Commercial General iLlability'coyerage ("occurrence"form CG 0001.)
2) Insurance Services Office form number CA 0001 (Ed. 1/78)
covering,Automobile Liability, code 1."any auto"and endorsement CA 0025.
i„ 3) Workers' Compensation insurance as required by the Labor
Code of the Statp of California and Employers Liability Insurance.
B. Minimum Limits of Insurance. Landowner shall maintain limits no
less than:
1) General Liability: $1,000,000 combined single limit per
occurrence for bodily injury, personal injury and property damage. If commercial
General Liability Insurance or other form with a general aggregate limit is used, either
the general aggregate limit shall apply separately to this project/location or the general
aggregate limit shall be twice the required occurrence limit.
2) Automobile Liability: $1,000,000 combined single limit per
accident for bodily injury and property damage.
6
3) Workers' Compensation and Employers Liability: Workers'
compensation limits as required by the Labor Code of the State of California and
Employers Liability limits of $1,000,000 per accident.
C. Deductibles and Self-Insurance Retentions. Any deductibles or
self-insured retentions must be declared to and approved by the City. At the option of
the City, Landowner shall procure a bond guaranteeing payment of losses and related
investigations, claim administration and defense expenses.
D. Other Insurance Provisions. The policies are to contain, or be
endorsed to contain, the following provisions:
1) General Liability and Autamobile Liability Coverages.
a) The City, its officers, agent , officials, employees and
volunteers shall be named as additional insureds in respect to; liability arising out of
activities performed by or on behalf of the' Landowner; products and completed
operations of the Landowner; premises owned, occupied or used by the Landowner; or
automobiles owned, leased, hired or borrowed by the Landowner.
The coverage shall Contain no special limitations on the
scope of the protection afforded' to the City, its officers, officials, employees or
volunteers.
b) The Landowner's insurance coverage shall be
primary insurance in respept to the City,its officer, officials, employees and volunteers.
Any insurance or,$elf-insurance maintained by the City, its officers, officials, employees
or volunteers shall be excess of the Landowner's insurance and shall not contribute with
it.
c) Any failure to comply with reporting provisions of the
policiea;ahall not affect coverage provided to,the City, its officers, officials, employees or
volunteers.
d) The Landowner's insurance shall apply separately to
each insured;against whom claim is made or suit is brought, except with respect to the
limits of the insrer's liability.
2) Workers' Compensation and Employers Liability Coverage.
The insurer shall agree to waive all rights of subrogation against the City, its officers,
officials, employees and `volunteers for losses arising from work performed by the
Landowner for the City.
3) All Coverages. Each insurance policy required by this
clause shall be endorsed to state that coverage shall not be suspended, voided,
cancelled by either party, reduced in coverage or in limits except after thirty (30) days'
prior written notice by certified mail, return receipt requested, has been given to the City.
a) Acceptability of Insurers. Insurance is to be placed
with insurers with a A.M. Bests' rating of no less than A:VII.
7
b) Verification of Coverage. Landowner shall furnish
City with certificates of insurance and with original endorsements effecting
coverage required by this clause. The certificates and endorsements for each insurance
policy are to be signed by a person authorized by that insurer to bind coverage on its
behalf. The certificates and endorsements are to be received and approved by the City
before work commences. The City reserves the right to require complete, certified
copies of all required insurance policies, at any time.
c) Subcontractors. Landowner and/or Landowner's
general contractor shall include all subcontractors as insureds under its policies or shall
obtain separate certificates and endorsements for each subcontractor. All coverages for
subcontractors shall be subject to all of the requirements stated herein.
18. Assignment of Agreement. This Agreement shall not be assigned by
y which shall not be unreasonably withheld.
Landowner without the written consent of City, w
19. Landowner Not an Agent. Neither Landowner nor any of Landowner's
agents or contractors are or shall be considered to be agents of City in connection with
the performance of Landowner's obligations under this Agreement.
20. Abandonment of Work. If Landowner refuses or fails to obtain
prosecution of the work, or any severable part thereof,(with such diligence as will insure
its completion within the time specified, or any extension thereof, or fails to obtain
completion of said work within such time, or if Landowner should be adjudged as
bankrupt, or should make a general assignment for the benefit of Landowner's creditors,
or if a receiver should be appointed, or' Landowner, or any of Landowner's contractors,
subcontractors, agents or employees should violate any of the provisions of this
Agreement, the City through its Public Works Director may serve written notice on
Landowner and Landowner's surety or holder of other security of breach of this
Agreement, or of any portion, thereof, and default of Landowner.
In the event of any such,fl notice of breach of this Agreement, Landowner's surety
shall have the duty to take the e over suret and complete the Improvements herein specified;
provided, however, that "rf
k y, within thirty (30) days after the serving upon it of
such notice of breach, does not give City written notice of its intention to take over the
performance of the contract, and does not commence performance thereof within thirty
(30) days after notice to City Of such election, City may take over the work and prosecute
the same to completion, by-Contract or by any other method City may deem advisable,
for the account and at the expense of Landowner and Landowner's surety shall be liable
to City for any damages and/or reasonable and documented excess costs occasioned
by City thereby; and, in such event, City, without liability for so doing, may take
possession of, and utilize in completing the work, such materials, appliances, plant and
other property belonging to Landowner as may be on the site of the work and necessary
therefor.
21. Notices. All notices herein required shall be in writing, and delivered in
person or sent by registered mail, postage prepaid.
Notices required to be given to City shall be addressed as follows:
City Manager
8
City of Dublin
100 Civic Plaza
Dublin, California 94568
Notices required to be given to Landowner shall be addressed as follows:
Bob Radanovich
BJP-ROF Jordan Ranch, LLC
5000 Hopyard Road, Suite 170
Pleasanton, CA 94588
Any party or the surety may change such addreselN notice in writing to the other
party and thereafter notices shall be addressed and transrnitted to the new address.
Concurrently with the execution of this Agreement, Landowner has executed,
and has caused to be acknowledged, an abstract of this Agreer lent. Landowner agrees
that City may record said abstract in the official records of Alameda,County.
22. Use of Improvements. At all times prior to the final acceptance of the work
by City, the use of any or all Improvements Within the work to be performed under this
Agreement shall be at the sole and exclusive risk of Landowner.
Li
23. Safety Devices. Landowner shall provide and maintain such guards,
watchmen, fences, barriers, regulatory signs, warning lights, and other safety devices
adjacent to and on the tract site as may be necessary to prevent accidents to the public
and damage to the p ,l?
may ra erty. Landowner shall_fyrnish, place, and maintain such lights
as ma be necessary for illuminating the,saidl fences; barriers, signs, and other safety
devices. At the end of all work to be performed under this Agreement, all fences,
barriers, regulatory signs, warning lights, and other safety devices (except such safety
items as may be shown on the plans and included in the items of work) shall be removed
the work by the and the',,entire site left clean and orderly.
from site pf't e wor y iTandovirhar, a
1111
Fees Attorneys' es and Venue In any action to enforce the provisions of this
Agreement, the prevailing party shall be entitled to its reasonable attorney's fees. Any
action 'arising out of this Agreement shall be brought in Alameda County, California
regardless(*where else venue may lie.
25. Recitals. The foregoing Recitals are true and correct and are made a part
hereof. 1
26. Severability. If a court of competent jurisdiction finds or rules that any
provision of this Agreement is invalid, void, or unenforceable, the provisions of this
Agreement not so adjudged shall remain in full force and effect. The invalidity in whole
or in part of any provision of this Agreement shall not void or affect the validity of any
other provision of this Agreement.
27. Counterparts. This Agreement may be executed in multiple counterparts,
each of which shall be an original and all of which together shall constitute one
agreement.
9
IN WITNESS WHEREOF, the City and Landowner have executed this Agreement, the
day and year first above written.
CITY OF DUBLIN
a Municipal Corporation
Dated: By:
Name: Christopher L. Foss
Title: City Manager
ATTEST:
By:
Name: Caroline P. Soto, City Clerk
Approved as to form
By:
Name: John Bakker, City Attorney
Y ,,
DEVELOPER
BJP-ROF Jordan Ranch, LLC
Dated: By:
Name:
Title:
255O$99.2
10
EXHIBIT B
05/2015
Jordan Ranch Neighborhood Park
BID TOTALS
Biditem Description Quantity Units Unit Price Bid Total
10 MOBILIZATION 1.000 LS 72,500.00 72,500.00
15 TEMP FENCE 1.000 LS 6,500.00 6,500.00
20 SURVEY 1.000 LS 20,000.00 20,000.00
30 SWPPP(QSP SERVICES&MAINTANCE) 1.000 LS 70,000.00 70,000.00
32 EROSION CONTROL BLANKET 14,300.000 SF 0.90 12,870.00
34 CONTRUCTION ENTRANCE 1.000 EA 3,200.00 3,200.00
36 INLET PROTECTION(incl.removal) 34.000 EA 375.00 12,750.00
38 STRAW WADDLES(incl.removal) 3,500.000 LF 5.80 20,300.00
39 TEMP HYDROSEED 1.000 SF 9,000.00 9,000.00
40 DEMO 1.000 LS 18,500.00 18,500.00
50 CLEAR&GRUB 4.700 AC 1,800.00 8,460.00
60 ROUGH GRADE 1.000 LS 30,000.00 30,000.00
65 OFF HAUL MATERIAL IN EXCESS 2,000.000 CY 6.75 13,500.00
70 SS-4"SDR 35 209.000 LF 32.00 6,688.00
80 SS-CLEAN OUT 3.000 EA 455.00 1,365.00
90 SS-MANHOLE 2.000 EA 12,000.00 24,000.00
100 SD-6" SOLID PVC 32.000 LF 19.50 624.00
110 SD-CLEAN OUT 1.000 EA 430.00 430.00
120 SD-8"SOLID PVC 542.000 LF 25.00 13,550.00
130 SD- 12"SOLID PVC 202.000 LF 42.00 8,484.00
140 SD- 15"SOLID PVC 145.000 LF 68.00 9,860.00
150 SD-CATCH BASIN 22.000 EA 1,800.00 39,600.00
160 RIP RAP OUTFALL 2.000 EA 1,750.00 3,500.00
170 POTABLE WATER METER&BACKFLOW(meter 1.000 EA 8,750.00 8,750.00
180 RECYCLED WATER METER&BACKFLOW(mete 1.000 EA 5,000.00 5,000.00
190 WATER- 1"BLDG SERVICE 236.000 LF 51.00 12,036.00
200 ELECTRICAL 1.000 LS 121,600.00 121,600.00
220 FINE GRADE 223,610.000 SF 0.40 89,444.00
225 6"AB-CONC. FLATWORK 13,190.000 SF 2.15 28,358.50
230 VEHICULAR CONCRETE PAVEMENT 7,340.000 SF 12.50 91,750.00
240 PEDESTRIAN CONCRETE PAVEMENT 5,396.000 SF 11.50 62,054.00
250 COLORED CONCRETE PAVEMENT 400.000 SF 17.50 7,000.00
260 CONCRETE MOW BAND 1,690.000 LF 16.50 27,885.00
270 CONCRETE HEADER AT BASKETBALL CT 300.000 LF 21.50 6,450.00
280 CONCRETE CURB AT PLAY AREA 120.000 LF 29.00 3,480.00
290 CONCRETE RETAINING CURB 20.000 LF 70.00 1,400.00
300 CONCRETE DRIVEWAY 1.000 EA 1,375.00 1,375.00
310 CONCRETE SEAT WALL 70.000 LF 190.00 13,300.00
320 CONCRETE STAIRS 1.000 LS 2,525.00 2,525.00
322 HANDRAIL FOR STAIRS 1.000 LS 1,875.00 1,875.00
325 CONCRETE CURB RAMP 1.000 LS 975.00 975.00
330 CONCRETE PARK SIGN ENTRY 1.000 LS 27,000.00 27,000.00
340 REMOVABLE BOLLARDS 6.000 EA 1,200.00 7,200.00
350 VOLLEYBALL POSTS&NET-COMPLETE IN PL 1.000 LS 3,400.00 3,400.00
355 BASKETBALL COURT(2.5"AC/ 12"AB) 5,640.000 SF 7.50 42,300.00
360 BASKETBALL HOOPS-COMPLETE IN PLACE 2.000 EA 4,445.00 8,890.00
362 BASKETBALL COURT STRIPING 1.000 LS 2,800.00 2,800.00
365 AC DRIVEWAY(3"AC/8"AB) 350.000 SF 7.00 2,450.00
370 BIOSWALE 1,540.000 SF 10.50 16,170.00
380 6"PERF PIPE(incl.CO&overflow system) 455.000 LF 26.50 12,057.50
385 CRUSH GRAVEL PAVING(2"FINES/3.5"GRAVE 2,570.000 SF 4.20 10,794.00
390 RESIL RUBBER SURFACE(incl.4"conc./4"AB) 5,200.000 SF 28.00 145,600.00
400 PLAYGROUND EQUIPMENT(MATERIALS ON H 1.000 LS 155,500.00 155,500.00
1
5/2015
Jordan Ranch Neighborhood Park
BID TOTALS
Biditem Description th.atittity Units Unit Price Bid Total
410 PLAYGROUND EQUIPMENT(INSTALL) 1.000 LS 25,800.00 25,800.00
420 SHADE STRUCTURE(INSTALL) 1.000 LS 8,000.00 8,000.00
430 RESTROOM BUILDING(COMPLETE IN-PLACE) 1.000 LS 151,000.00 151,000.00
435 QUARRY TILE FLOOR IN BLDG(CITY OPTION) 1.000 LS 5,360.00 5,360.00
440 IRRIGATION 1.000 LS 241,000.00 241,000.00
445 RW HEADER BOARD 120.000 LF 22.50 2,700.00
450 PLANTING 1.000 LS 106,500.00 106,500.00
460 90 DAY MAINTENANCE 1.000 LS 29,000.00 29,000.00
470 ACCESSIBLE PICNIC TABLE 2.000 EA 3,800.00 7,600.00
480 PICNIC TABLE 5.000 EA 3,850.00 19,250.00
490 SERVING TABLE 2.000 EA 2,650.00 5,300.00
500 BBQ 2.000 EA 1,400.00 2,800.00
510 BIKE RACK 4.000 EA 600.00 2,400.00
520 BENCH w/BACK 1.000 EA 2,125.00 2,125.00
530 BENCH w/o BACK 6.000 EA 2,025.00 12,150.00
540 TRASH/RECYCLING RECEPTACLES 4.000 EA 3,950.00 15,800.00
550 DOG WASTE DISPENSER 1.000 EA 600.00 600.00
Bid Total =------_> $1,962,485.00
2